Browse City of Leesburg civic records
Every published record for City of Leesburg, newest first. Filter by board, year, or industry to jump straight to the records you want, and page through to reach the full archive.
961 records
C. NON-ROUTINE ITEMS:
City Commission Meeting listed this item on its agenda for 2026-08-10 in City of Leesburg. The posted record gives the item title and nothing else, so there is no site, no size and no applicant on file for it yet. Local businesses that want to follow it can open the official agenda link above and watch for the fuller write-up the body posts as the meeting gets closer.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_item
Carver Heights Montclair Area CRA Agenda 08 10 26
Carver Heights/Montclair Area CRA in City of Leesburg posted this record to its public file. The posted document carries a title and no readable project detail, so there is no site, no size and no applicant on file for it yet. Local businesses that want to follow it can open the official document link above and watch for the fuller record the body posts later.
- Board:
- Carver Heights/Montclair Area CRA
- Date:
- 2026-08-10
- Type:
- Agenda
Carver Heights/Montclair Area CRA
The Carver Heights/Montclair Area CRA, City of Leesburg, Lake met recently to discuss contract documents and project timelines. The meeting covered general contractor requirements, including insurance, payment terms, and performance schedules. Future opportunities may involve work related to the Carver Heights/Montclair Area Community Redevelopment, with potential needs for various trades and suppliers.
- Board:
- Carver Heights/Montclair Area CRA
- Date:
- 2026-08-10
- Type:
- Meeting
City Commission Agenda Packet 08 10 26
[City Hall, 501 W Meadow Street, Leesburg, FL (meeting location; not a project site)] This document is a public record of two City of Leesburg budget workshop meetings (FY 2026-27), not a record of a specific development project. The first meeting (Workshop #3) covered water, wastewater, solid waste, stormwater, pension funds, health insurance, workers' compensation, and fleet budgets. The second meeting (Workshop #4) was a joint workshop with the Community Redevelopment Agencies (CRAs) covering the Greater Leesburg CRA, Carver Heights/Montclair Area CRA, and U.S. Highway 441/27 CRA budgets. The document contains no specific project address, parcel, size, zoning change, applicant, case number, or decision. It is a procedural and administrative record of budget discussions. Key facts include proposed 3% rate increases for water, wastewater, and solid waste for FY27; a solid waste monthly rate of $20.61; a $600,000 estimated cost for the Lake Hollywood stormwater project; a $1.2 million internal loan for the Carver Heights Resource Center; a $600,000 allocation for the Carver Heights Home Grant Program; and a $50,000 allocation from the Highway 441 CRA for grants. Public comment sentiment includes Commissioner Sokol's concerns about disparities on the east side and a desire for a grant program for east side property owners, Commissioner Ponder's concerns about CRA spending priorities and the need to update the CRA plan, and Commissioner Connell's request to discontinue a library magazine subscription. [Reserve at 44: east of County Road 44 and north of Spring Court; Perry-Smith: west of U.S. Highway 27 and south of the Florida Turnpike; Goodman: south of E North Boulevard, east of E Dixie Avenue, and north of E Main Street; JCQ Leesburg: north of Plantation View Drive, south of Palmetto Drive, and west of U.S. Highway 27; Merritt Ranch: south of CR 48, north of Shady Grove Road, and east of the Sumter County Line; case Reserve at 44: RZ-26-985 (referenced in public comment); Perry-Smith: not stated; Goodman: not stated; JCQ Leesburg: not stated; Merritt Ranch: not stated] The document is a City of Leesburg Commission meeting minutes covering multiple projects. The Reserve at 44 project (10.24 acres, east of CR 44 and north of Spring Court, Section 1, Township 19 South, Range 25 East) had its annexation, land use, and zoning hearings continued to August 10, 2026, at the petitioner's request. The Perry-Smith project (7.53 acres, west of US Highway 27 and south of Florida Turnpike, Section 7, Township 21 South, Range 25 East) was approved for annexation, a land use change from Lake County Urban Low Density to City General Commercial, and a zoning change from Lake County Agriculture to SPUD, allowing approximately 20,000 square feet of commercial and medical office uses. The Goodman rezoning (0.30 acres, south of E North Boulevard, east of E Dixie Avenue, north of E Main Street, Section 25, Township 19 South, Range 24 East) was approved to change zoning from R-3 to C-3. The JCQ Leesburg project (65 acres, north of Plantation View Drive, south of Palmetto Drive, west of US Highway 27, Section 36, Township 20 South, Range 24 East) was transmitted to reviewing agencies for a large-scale comprehensive plan amendment, proposing 131 residential units and approximately 38,000 square feet of commercial space. The Merritt Ranch project (118.05 acres for annexation, 445 acres total, south of CR 48, north of Shady Grove Road, east of Sumter County Line, Section 07, Township 21 South, Range 24 East) was transmitted for a large-scale comprehensive plan amendment, proposing 523 detached single-family residential units. Public comment included opposition to the JCQ Leesburg project from Plantation at Leesburg residents, with a petition of 290 signatures, leading to conditions such as a 25-foot buffer, 70-foot lots, and an opaque fence. Other public comments concerned BookPage magazine, Flock cameras, and utility installations in Palmora Park. [Merritt Ranch: generally located south of CR 48, west of North Austin Merritt Road, and east of Sumter County Line, lying in Section 07, Township 21 South, Range 24 East, Lake County, Florida. Palmetto Pickleball Courts: corner of South Palmetto Street and Woodard Street.; case Merritt Ranch: not stated. Palmetto Pickleball Courts: RFP 26-008-HG, Contract No. AP26008, Project No. 310081, WF No. WF1677121, Requisition 58065.] The document is a public civic record from the City of Leesburg, Florida, containing two distinct projects: (1) a City Commission meeting where the Merritt Ranch PUD was transmitted for state review, and (2) a Construction Services Agreement for the Palmetto Pickleball Courts. The Merritt Ranch project involves a 445.38-acre property, with 327.33 acres in the City and 118 acres proposed for annexation, changing zoning from Lake County A (Agriculture) and City R-1-A (Single Family Residential) to City of Leesburg PUD (Planned Unit Development) to allow 523 single-family homes. The City Commission voted 3-1 to transmit the application. The Palmetto Pickleball Courts project is a design-build contract for eight to twelve lighted pickleball courts and resurfacing of four tennis courts at the corner of South Palmetto Street and Woodard Street, with a contract awarded to D&A Construction Group, Inc. dba DACG, Inc. for $1,127,570.00, despite the resolution authorizing Nidy Sports Construction Company, LLC for an amount not to exceed $1,395,000.00. The document also includes public comment from Attorney Tara Tedrow, representing the applicant, who emphasized the net reduction in development intensity and the preservation of open space. No public comment sentiment is stated for the pickleball courts project. [case Contract No. AP26008; RFP 26-008-HG] The document is a construction services agreement for the Palmetto Pickleball Courts design-build project. The project is located in Leesburg, Florida, but no specific street address, parcel, or folio is stated. The contract value is $2,847,000.00. The applicant/developer/owner is the City of Leesburg, and the contractor is D.E. Scorpio Corporation dba Scorpio. The case/file number is Contract No. AP26008 and RFP 26-008-HG. The decision is not stated; the agreement is executed as of August 10, 2026. The work must commence within 21 days of Notice to Proceed, achieve substantial completion within 90 days, and final completion within 30 days after substantial completion. Liquidated damages are $1,685 per calendar day. The document contains no public comment or stakeholder sentiment. The business opportunity is the construction of pickleball courts, with a contract value of $2,847,000.00, requiring performance and payment bonds and specific insurance. The document is silent on the exact location, size, and zoning change. [Leesburg International Airport; case 3-12-0042-036-2026] The document is a Federal Aviation Administration (FAA) FY 2026 Airport Infrastructure Grant (AIG) Grant Agreement for the Leesburg International Airport. The project is to 'Rehabilitate Westside T-hangar Taxilanes Phase 2 (2,375 feet) - Construction'. The sponsor is the City of Leesburg. The FAA will pay 95% of allowable costs, with a maximum obligation of $958,621. The grant number is 3-12-0042-036-2026. The offer expires on August 27, 2026. The period of performance is four years from the date of acceptance. The document includes numerous standard federal grant terms and conditions, including reporting, audit, closeout, Buy American, and environmental compliance requirements. No public comment or stakeholder sentiment is stated in the document. [Leesburg International Airport, 8807 Airport Blvd., Leesburg, FL 34788; case IFB 26-014-DN; Resolution No. ____________ (not stated); Project No. 480003; WF No. 1640659/2; Requisition 58559 and 58746] The document is a set of FAA grant assurances and a City of Leesburg agenda memorandum for a Taxilanes Rehabilitation Project at Leesburg International Airport. The project involves rehabilitating taxilanes serving hangars north of the main aircraft parking apron and the box hangars and t-hangar north of Airport Boulevard. The City Commission is being asked to authorize a construction agreement with C.W. Roberts Contracting, Inc. for an amount not to exceed $870,575.00, and a task order with AVCON, Inc. for construction administration services for an amount not to exceed $115,950.00. The project is funded by a FAA reimbursable grant (95%) with the Airport's cost being 5%. The staff recommendation is to approve both items. The document does not state a decision, as it is an agenda memorandum for a meeting on August 10, 2026. [Leesburg International Airport (for West Taxilanes Rehabilitation); Orange Bend Ranch is located in Leesburg, Florida, commonly identified by Alternate Key(s) 1387060; Reserve at 44 is generally located east of County Road 44 and north of Spring Court.; case Case #2023-25 for Orange Bend Ranch; Item No: 5.C.4 for the Orange Bend Ranch resolution; Item No: 5.C.5 for the library services resolution; Item No: 6.A.1 for the Historic Structure Density Bonus ordinance; Item No: 6.A.2 for the Reserve at 44 annexation ordinance.] The document is a multi-item agenda for the City of Leesburg City Commission meeting on August 10, 2026. It includes a construction services proposal for the West Taxilanes Rehabilitation at Leesburg International Airport, a resolution to approve the First Amendment to the Proportionate Share Mitigation Agreement for Orange Bend Ranch, a resolution to authorize the Fifth Amendment to the Interlocal Agreement for library services, an ordinance to create a Historic Structure Density Bonus program, and an ordinance for the annexation of the Reserve at 44 property. The document does not state a decision for any item, as it is an agenda with staff recommendations. Public comment sentiment is not stated in the document. [Not stated. The property is generally located east of County Road 44 and north of Spring Court, Leesburg, Florida.; case ANNX-26-955; SSCP-26-956; PUD-26-957.] The document is a City of Leesburg agenda memorandum covering three related items for the Reserve at 44 project: annexation (ANNX-26-955), small-scale comprehensive plan amendment (SSCP-26-956), and Planned Unit Development rezoning (PUD-26-957). The property is approximately 10.24 acres, generally located east of County Road 44 and north of Spring Court, in Section 1, Township 19 South, Range 25 East, Lake County, Florida. The applicant/petitioner is GDFSL LLC, 1810 W Kennedy Blvd, Suite 232, Tampa, FL 33606 (Jason M. Lee). The annexation ordinance would place the property in City Commission District 5. The comprehensive plan amendment would change the Future Land Use Map designation from Lake County Urban Low to City of Leesburg Estate Residential. The rezoning would change the zoning from Lake County R-1 (Rural Residential) and R-3 (Medium Residential) to City of Leesburg PUD (Planned Unit Development) to allow for 23 single-family residential units on 60' x 120' lots. Staff recommended approval for all three items. The Planning Commission recommended denial, 3-2, citing concerns regarding lot size, density, and traffic. The PUD agreement includes conditions for a maximum of 23 detached single-family units, minimum lot size of 7,200 square feet, minimum house size of 1,400 square feet, 35% open space, a 25-foot buffer, a split-rail fence along CR-44, a decorative entry feature, natural gas connection for at least 80% of units, and a development permit application within 4 years of approval. The ordinances are dated for adoption at a meeting on August 10, 2026. The PUD ordinance text states it was passed and adopted on July 10, 2026, but the agenda memorandum meeting date is August 10, 2026. The document does not state a final decision on the annexation or the comprehensive plan amendment. The PUD agreement is dated May 21, 2026, and is granted by the Planning Commission. The document does not state a final decision on the PUD rezoning by the City Commission. The document does not state a street address. The legal description references Lots 3 and 4 of Block 19 in the Revised and Corrected Plat of the Re-subdivision of the Subdivision of Silver Lake Estates, Plat Book 10, Pages 66 through 69. The Alternate Key Number is 1273536.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_packet
- Decision:
- Reserve at 44: continued to August 10, 2026; Perry-Smith: approved (Ordinances 26-22, 26-23, 26-24); Goodman: approved (Ordinance 26-25); JCQ Leesburg: transmitted to reviewing agencies; Merritt Ranch: transmitted to reviewing agencies
- Address:
- City Hall, 501 W Meadow Street, Leesburg, FL (meeting location; not a project site)
- Applicant:
- Reserve at 44: not stated; Perry-Smith: Mike Rankin of Land Planning Group; Goodman: not stated; JCQ Leesburg: Mike Rankin of Land Planning Group; Merritt Ranch: not stated
City Commission Agenda Packet 08-10-26
[Perry-Smith: west of U.S. Highway 27 and south of the Florida Turnpike; Goodman: south of E North Boulevard, east of E Dixie Avenue, and north of E Main Street; JCQ Leesburg: north of Plantation View Drive, south of Palmetto Drive, and west of U.S. Highway 27; Reserve at 44: east of County Road 44 and north of Spring Court; Merritt Ranch: south of CR 48, north of Shady Grove Road, and east of the Sumter County Line; 21103 Hollywood Drive; case Reserve at 44: RZ-26-985; other case numbers not stated] This document is a set of City of Leesburg Commission meeting minutes covering multiple agenda items. It includes approvals for the Perry-Smith project (7.53 acres, west of US Highway 27 and south of Florida Turnpike, Section 7, Township 21 South, Range 25 East, Lake County, Florida; from Lake County Urban Low Density to City General Commercial and from Lake County Agriculture to SPUD; applicant Mike Rankin of Land Planning Group; adopted ordinances 26-22, 26-23, 26-24), the Goodman rezoning (0.30 acres, south of E North Boulevard, east of E Dixie Avenue, north of E Main Street, Section 25, Township 19 South, Range 24 East, Lake County, Florida; from City R-3 to C-3; adopted ordinance 26-25), and a motion to transmit the JCQ Leesburg project (65 acres, north of Plantation View Drive, south of Palmetto Drive, west of US Highway 27, Section 36, Township 20 South, Range 24 East, Lake County, Florida; from Lake County Urban Low Density to City Estate Residential and from Lake County Agriculture to PUD; applicant Mike Rankin of Land Planning Group; motion to transmit approved with three yeas and one nay). The document also includes continuations for the Reserve at 44 project (10.24 acres, east of County Road 44 and north of Spring Court, Section 1, Township 19 South, Range 25 East, Lake County, Florida; from Lake County Urban Low to City Estate Residential and from Lake County R-1 and R-3 to City PUD; continued to August 10, 2026) and a transmittal for the Merritt Ranch project (118.05 acres for annexation, south of CR 48, north of Shady Grove Road, east of Sumter County Line, Section 07, Township 21 South, Range 24 East, Lake County, Florida; from Lake County Rural and City Neighborhood Mixed Use to City Estate and from Lake County Agriculture and City R-1A to City PUD; motion to transmit approved). Other items include a resolution for the disposition of surplus City-owned lots (Resolution 12,259), a construction services agreement with EZ Contracting LLC for replacement of 3,500 linear feet of 12-inch water main (Resolution 12,257), a construction services agreement with PAQCO, Inc. for street resurfacing and striping for $210,766.50 (Resolution 12,258), a School Resource Officer services agreement (Resolution 12,260), and a utility easement acceptance from The Salvation Army (Resolution 12,261). Public comment included opposition to the JCQ Leesburg project from Plantation at Leesburg residents, with a petition of 290 signatures, concerns about wildlife, traffic, noise, and buffering, which led to conditions such as a 25-foot buffer, 70-foot lots, and an opaque fence. Public comment also included concerns about BookPage magazine, Flock cameras, and utility installations in Palmora Park. The document also discusses CRA budgets and lot donation policies. The meeting adjourned at 6:14 p.m. on July 27, 2026. [Project 1: Generally located south of CR 48, west of North Austin Merritt Road, and east of Sumter County Line. Project 2: Corner of South Palmetto Street and Woodard Street.; case Project 1: Merritt Ranch LSCP and Merritt Ranch PUD. Project 2: RFP 26-008-HG, Contract No. AP26008, Project No. 310081, WF No. WF1677121, Requisition 58065.] The document is a multi-item public record from the City of Leesburg, Florida, containing two distinct projects. Project 1: Merritt Ranch, a proposed Planned Unit Development (PUD) for 523 single-family homes on 445.38 acres, generally located south of CR 48, west of North Austin Merritt Road, and east of Sumter County Line, in Section 07, Township 21 South, Range 24 East, Lake County, Florida. The City Commission voted to transmit the application (three yeas, one nay) for state review. The project involves annexation of 118 acres from Lake County, a future land use map amendment for the City portion from Neighborhood Mixed Use to Estate Residential, and rezoning from Lake County A (Agriculture) and City R-1-A (Single Family Residential) to City of Leesburg PUD. The applicant's attorney was Tara Tedrow of Lowndes, Drosdick, Doster, Kantor & Reed. The Planning and Zoning Board unanimously recommended approval. Project 2: Palmetto Pickleball Courts, a design-build construction project for eight to twelve lighted pickleball courts and resurfacing of four tennis courts at the corner of South Palmetto Street and Woodard Street. The City Commission approved a resolution authorizing a Construction Services Agreement with Nidy Sports Construction Company, LLC for an amount not to exceed $1,395,000.00. However, the contract included in the document is between the City and D&A Construction Group, Inc dba DACG, Inc. for a total price not to exceed $1,127,570.00. The project budget was $1,000,000.00. The contract requires commencement within 21 days of Notice to Proceed, substantial completion within 90 days, and final completion within 30 days after substantial completion. Liquidated damages are $1,685 per calendar day for late completion. [case Contract No. AP26008; RFP 26-008-HG] The document is a construction services agreement for the Palmetto Pickleball Courts design-build project. The contract is between the City of Leesburg and D.E. Scorpio Corporation dba Scorpio. The total construction cost is not to exceed $2,847,000.00. The contractor must commence work within 21 days of Notice to Proceed, achieve substantial completion within 90 days, and final completion within 30 days after substantial completion. Liquidated damages are $1,685 per calendar day for late completion. The agreement is dated August 10, 2026. The project is referenced as Contract No. AP26008 and RFP 26-008-HG. The document does not state a specific street address, parcel, acreage, number of units, or zoning change. No public comment or stakeholder sentiment is stated. [2042 East Silver Springs Blvd, Ocala, FL 34470 (contractor); 501 West Meadow Street, Leesburg, Florida 34748 (city)] The document is a public contract agreement between the City of Leesburg, Florida and D.E. Scorpio Corporation dba Scorpio, containing general terms and conditions for construction services. It does not describe a specific project, site, or action beyond the administrative contract terms. The document states the contractor's address as 2042 East Silver Springs Blvd, Ocala, FL 34470, and the city's address as 501 West Meadow Street, Leesburg, Florida 34748. No project size, zoning change, case number, decision, or key dates are stated. [case Contract No. AP26008; RFP 26-008-HG] This document is a construction services agreement between the City of Leesburg and William Medley Construction, Inc. dba Medley Sports Construction for the design-build of the Palmetto Pickleball Courts. The contract number is AP26008, and it references RFP 26-008-HG. The total construction cost is not to exceed $1,000,000.00. The contractor must commence work within 21 days after Notice to Proceed, achieve Substantial Completion within 90 days, and Final Completion within 30 days after substantial completion. Liquidated damages are $1,685 per calendar day. The agreement is dated August 10, 2026. The document does not state a specific street address, parcel, acreage, or zoning change for the project. It includes extensive contract terms on inspections, defective work, arbitration, insurance, and termination. No public comment or stakeholder sentiment is stated in the document. [Leesburg International Airport; case 3-12-0042-036-2026] The document is a Federal Aviation Administration (FAA) FY 2026 Airport Infrastructure Grant (AIG) Grant Agreement for a project at Leesburg International Airport. The project is to 'Rehabilitate Westside T-hangar Taxilanes Phase 2 (2,375 feet) - Construction'. The sponsor is the City of Leesburg. The FAA's maximum obligation is $958,621, which is 95% of allowable costs. The grant number is 3-12-0042-036-2026. The offer expires on August 27, 2026, unless accepted. The period of performance ends four years from the date of acceptance. The project application date is June 1, 2026. The FAA program manager is Jennifer Ganley. The document includes numerous standard federal grant conditions and assurances, including reporting, audit, Buy American, and environmental compliance requirements. No public comment or stakeholder sentiment is stated in the document. [Not stated for the construction services proposal. Not stated for the Orange Bend Ranch project, but the property is located in Leesburg, Florida. Not stated for the library services agreement. Not stated for the historic density bonus ordinance. The property for the Reserve at 44 annexation is generally located east of County Road 44 and north of Spring Court.; case Not stated for the construction services proposal. Case #2023-25 for Orange Bend Ranch. Not stated for the library services agreement. Not stated for the historic density bonus ordinance. Not stated for the Reserve at 44 annexation.] The document is a multi-item agenda for a City of Leesburg, Florida City Commission meeting on August 10, 2026. It includes a construction services fee proposal for the West Taxilanes Rehabilitation at Leesburg International Airport, a resolution to extend a proportionate share mitigation agreement for the Orange Bend Ranch project, a resolution to extend a library services interlocal agreement, an ordinance to create a historic structure density bonus, and an ordinance to annex property for the Reserve at 44 project. The document does not state a decision for any item, only staff recommendations for approval. [Generally located east of County Road 44 and north of Spring Court, Lake County, Florida; case ANNX-26-955; SSCP-26-956; PUD-26-957] The document is a City of Leesburg agenda memorandum packet covering three related items for the Reserve at 44 project: annexation (ANNX-26-955), small-scale comprehensive plan amendment (SSCP-26-956), and PUD rezoning (PUD-26-957). The property is approximately 10.24 acres, generally located east of County Road 44 and north of Spring Court, lying in Section 1, Township 19 South, Range 25 East, Lake County, Florida. The applicant/petitioner is GDFSL LLC, 1810 W Kennedy Blvd, Suite 232, Tampa, FL 33606 (Jason M. Lee, Petitioner). The annexation ordinance (Item 6.A.3) would annex the property into the City of Leesburg, placing it in City Commission District 5. The comp plan amendment (Item 6.A.3) would change the Future Land Use Map designation from Lake County Urban Low to City of Leesburg Estate Residential. The PUD rezoning (Item 6.A.4) would change zoning from Lake County R-1 (Rural Residential) and R-3 (Medium Residential) to City of Leesburg PUD (Planned Unit Development) to allow for 23 single-family residential units on 60' x 120' lots. The PUD agreement (Exhibit A) specifies a maximum of 23 detached single-family residential units at a gross density of 2.3, with minimum lot size 7,200 square feet, minimum house size 1,400 square feet, and a minimum 25-foot wide buffer tract along property boundaries. The Planning Commission at the public hearing held on May 21, 2026, recommended denial, 3-2, citing concerns regarding lot size, density, and traffic. Staff recommended approval for all three items. The ordinances are dated for passage at a regular meeting held August 10, 2026, though the PUD ordinance text states 'PASSED AND ADOPTED at the regular meeting... held on the 10th day of July 2026.' The annexation ordinance states it becomes effective immediately upon approval at second reading. The comp plan amendment and PUD ordinance state they become effective upon passage and adoption. The PUD agreement includes a condition that a development permit or building permit application must be submitted within four (4) years of approval becoming final, or the PUD will expire and the property will be governed by RE-1 (Estate Density Residential) zoning. The document does not state a final decision by the City Commission on any of the three items; it presents staff recommendations and options for the Commission. The document does not state any public comment from citizens or stakeholders beyond the Planning Commission's stated concerns.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_packet
- Decision:
- Perry-Smith: adopted (Ordinances 26-22, 26-23, 26-24); Goodman: adopted (Ordinance 26-25); JCQ Leesburg: motion to transmit approved (three yeas, one nay); Reserve at 44: continued to August 10, 2026; Merritt Ranch: motion to transmit approved; water main: adopted (Resolution 12,257); street resurfacing: adopted (Resolution 12,258); surplus lots: adopted (Resolution 12,259); SRO agreement: adopted (Resolution 12,260); utility easement: adopted (Resolution 12,261)
- Address:
- Perry-Smith: west of U.S. Highway 27 and south of the Florida Turnpike; Goodman: south of E North Boulevard, east of E Dixie Avenue, and north of E Main Street; JCQ Leesburg: north of Plantation View Drive, south of Palmetto Drive, and west of U.S. Highway 27; Reserve at 44: east of County Road 44 and north of Spring Court; Merritt Ranch: south of CR 48, north of Shady Grove Road, and east of the Sumter County Line; 21103 Hollywood Drive
- Applicant:
- Perry-Smith: Mike Rankin of Land Planning Group; Goodman: not stated; JCQ Leesburg: Mike Rankin of Land Planning Group; Reserve at 44: not stated; Merritt Ranch: not stated
P: 407.740.5400
City Commission Meeting listed this item on its agenda for 2026-08-10 in City of Leesburg. The posted record gives the item title and nothing else, so there is no site, no size and no applicant on file for it yet. Local businesses that want to follow it can open the official agenda link above and watch for the fuller write-up the body posts as the meeting gets closer.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_item
a. Rating: The Surety must be rated as "A" or better as to strength by Best's
City Commission Meeting listed this item on its agenda for 2026-08-10 in City of Leesburg. The posted record gives the item title and nothing else, so there is no site, no size and no applicant on file for it yet. Local businesses that want to follow it can open the official agenda link above and watch for the fuller write-up the body posts as the meeting gets closer.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_item
a. Scope of Insurance - The CONTRACTOR shall procure and maintain at its own
City Commission Meeting listed this item on its agenda for 2026-08-10 in City of Leesburg. The posted record gives the item title and nothing else, so there is no site, no size and no applicant on file for it yet. Local businesses that want to follow it can open the official agenda link above and watch for the fuller write-up the body posts as the meeting gets closer.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_item
a. This Agreement; and
City Commission Meeting listed this item on its agenda for 2026-08-10 in City of Leesburg. The posted record gives the item title and nothing else, so there is no site, no size and no applicant on file for it yet. Local businesses that want to follow it can open the official agenda link above and watch for the fuller write-up the body posts as the meeting gets closer.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_item
b. B
City Commission Meeting listed this item on its agenda for 2026-08-10 in City of Leesburg. The posted record gives the item title and nothing else, so there is no site, no size and no applicant on file for it yet. Local businesses that want to follow it can open the official agenda link above and watch for the fuller write-up the body posts as the meeting gets closer.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_item
b. Certificate of Insurance - The CONTRACTOR shall provide evidence of required
City Commission Meeting listed this item on its agenda for 2026-08-10 in City of Leesburg. The posted record gives the item title and nothing else, so there is no site, no size and no applicant on file for it yet. Local businesses that want to follow it can open the official agenda link above and watch for the fuller write-up the body posts as the meeting gets closer.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_item
b. Request for Proposal ( RFP) 26-008-HG, Palmetto Pickleball Courts – Design
The City of Leesburg is planning a new project called Palmetto Pickleball Courts. This project is a Design Build request for proposal, meaning the selected contractor will be responsible for both the design and construction of the courts. The project is currently in the planning stage, indicated by the Request for Proposal (RFP) process. This early phase means there is an opportunity for contractors, suppliers, and service providers to engage before final plans and bids are set. The work will likely involve site preparation, grading, concrete work for courts, fencing, lighting, and potentially related amenities. Businesses involved in site work, concrete, electrical, fencing, and general construction could find opportunities. Engaging now allows businesses to understand the project scope and potentially influence the process before formal bidding begins.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_item
c. CONTRACTOR’s response to RFP 26-008-HG included as Exhibit ‘A’; and
City Commission Meeting listed this item on its agenda for 2026-08-10 in City of Leesburg. The posted record gives the item title and nothing else, so there is no site, no size and no applicant on file for it yet. Local businesses that want to follow it can open the official agenda link above and watch for the fuller write-up the body posts as the meeting gets closer.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_item
c. Comprehensive General Liability - The CONTRACTOR shall purchase and
City Commission Meeting listed this item on its agenda for 2026-08-10 in City of Leesburg. The posted record gives the item title and nothing else, so there is no site, no size and no applicant on file for it yet. Local businesses that want to follow it can open the official agenda link above and watch for the fuller write-up the body posts as the meeting gets closer.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_item
d. All addendums; and
City Commission Meeting listed this item on its agenda for 2026-08-10 in City of Leesburg. The posted record gives the item title and nothing else, so there is no site, no size and no applicant on file for it yet. Local businesses that want to follow it can open the official agenda link above and watch for the fuller write-up the body posts as the meeting gets closer.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_item
d. Business Automobile Liability - The CONTRACTOR shall purchase and
City Commission Meeting listed this item on its agenda for 2026-08-10 in City of Leesburg. The posted record gives the item title and nothing else, so there is no site, no size and no applicant on file for it yet. Local businesses that want to follow it can open the official agenda link above and watch for the fuller write-up the body posts as the meeting gets closer.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_item
e. Exhibit B – Supplemental Conditions – Construction
City Commission Meeting listed this item on its agenda for 2026-08-10 in City of Leesburg. The posted record gives the item title and nothing else, so there is no site, no size and no applicant on file for it yet. Local businesses that want to follow it can open the official agenda link above and watch for the fuller write-up the body posts as the meeting gets closer.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_item
e. W
City Commission Meeting listed this item on its agenda for 2026-08-10 in City of Leesburg. The posted record gives the item title and nothing else, so there is no site, no size and no applicant on file for it yet. Local businesses that want to follow it can open the official agenda link above and watch for the fuller write-up the body posts as the meeting gets closer.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_item
i. All required insurance shall be provided by insurers acceptable to the
City Commission Meeting listed this item on its agenda for 2026-08-10 in City of Leesburg. The posted record gives the item title and nothing else, so there is no site, no size and no applicant on file for it yet. Local businesses that want to follow it can open the official agenda link above and watch for the fuller write-up the body posts as the meeting gets closer.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_item
i. Except for workers’ compensation and professional liability, the
City Commission Meeting listed this item on its agenda for 2026-08-10 in City of Leesburg. The posted record gives the item title and nothing else, so there is no site, no size and no applicant on file for it yet. Local businesses that want to follow it can open the official agenda link above and watch for the fuller write-up the body posts as the meeting gets closer.
- Board:
- City Commission Meeting
- Date:
- 2026-08-10
- Type:
- Agenda_item
Mira los negocios reales detrás de estos números
Obtén los registros reales, con direcciones y directivos, respaldados por una garantía de reembolso de 14 días.
Crea tu cuenta