Browse Sumter County civic records
Every published record for Sumter County, newest first. Filter by board, year, or industry to jump straight to the records you want, and page through to reach the full archive.
57 records
May 26, 2026 Regular Meeting Agenda packet 2026-05-26
[6075 C-575; case LU26-000010 and ZON26-000010] The Sumter County Board of County Commissioners considered a Small-Scale Future Land Use Change and a Zoning Change for a 20.07-acre parcel owned by Mary Holcomb. The request was to change the Future Land Use from Agriculture to Rural Residential and the zoning from General Agriculture (A10C) and Rural Residential (RR5C) to Rural Residential (RR1C). Both the Planning and Zoning Special Master and County Staff recommended approval. The proposed change aims to facilitate a lot split and residential development consistent with rural densities. Concerns were raised by Stephen Vizzi regarding proper notification, potential environmental and roadway impacts, and the density of the proposed development not aligning with the rural character. Glenna Blackwelder also expressed opposition due to potential negative impacts on surrounding properties and community character. The Planning and Zoning Special Master recommended approval, finding the amendment consistent with the Comprehensive Plan and not contributing to urban sprawl. The Board of County Commissioners meeting was scheduled for May 26, 2026. [6075 C 575; case LU26-000010, ZON26-000010] The Sumter County Board of County Commissioners approved a rezoning and future land use change for a 20.07-acre parcel. The property, owned by Mary Holcomb, was rezoned from General Agriculture (A10C) and Rural Residential (RR5C) to Rural Residential Minimum One Acre (RR1C). This change facilitates a lot split and low-density residential development. The decision was made on May 26, 2026, following a recommendation from the Planning and Zoning Special Master on May 4, 2026. Public comments expressed opposition due to concerns about negative impacts on property values, increased traffic, and disruption of the rural character. One commenter also raised issues regarding notification procedures and the environmental impact of dense residential development. [Lake Okahumpka, Wildwood, FL] This document is a petition from 'SAVE OUR LAKE OKAHUMPKA' (SOLO) and the Lake Okahumpka Conservation Committee (LOCC) to various state and local officials, including the Governor of Florida, FWC, Sumter County Board of County Commissioners, and the City of Wildwood Commission. The petition highlights the ecological and recreational collapse of Lake Okahumpka due to invasive vegetation (Hydrilla and Water Hyacinth) and floating 'tussocks' of mud and decaying plant matter. These obstructions have rendered the lake unnavigable and are decreasing its depth. The petitioners demand immediate mechanical harvesting, a feasibility study and funding for dredging, long-term invasive management, and parity in environmental priority and funding with the Harris Chain of Lakes. They warn of economic loss, ecological collapse, and public safety hazards if no action is taken. Mary Lanning, representing LOCC, stated that the lake is at a tipping point and risks losing its recreational and ecological value. [Lake Okahumpka, 50 Continental Blvd, Wildwood, FL 34785 (Continental Country Club); case 0450206-001-UC/5EX, 0450206-001-UC/M5] This document is a collection of communications regarding environmental concerns in Sumter County, Florida. It includes a petition from "SAVE OUR LAKE OKAHUMPKA" and the "Lake Okahumpka Conservation Committee (LOCC)" demanding action to address the ecological and recreational collapse of Lake Okahumpka due to invasive vegetation, muck accumulation, and decreased depth. It also includes emails concerning odor complaints related to a waste operation, and concerns about well collapses potentially linked to underground injection well drilling near the Heart of Florida Landfill. No specific project approvals or denials are detailed, but the communications highlight significant public concern and ongoing investigations. This document contains multiple unrelated items. Part 5 of 16 consists of questions for the Florida Department of Environmental Protection regarding proposed injection well activities at Heart of Florida Landfill in Sumter County, Florida. It does not contain specific project details for contractors. The subsequent sections detail legal proceedings and administrative matters within Sumter County, Florida, including a sidewalk transfer, a legal memorandum regarding waste importation, a civil case management order, a stipulated final judgment for a zoning violation, and a petition regarding an animal in custody. None of these sections describe new construction or renovation projects for contractors. [201 Lemons Street, Wildwood, Florida 34785; case not stated (Sumter County Animal Control Case #5878)] Sumter County, Florida, is petitioning the County Court to determine if the owners are fit to provide for an animal and if not, to grant Sumter County custody and ownership for disposition. The county also seeks costs of care and attorney fees. This is related to Sumter County Animal Control Case #5878 concerning a neglected or mistreated animal named Midas. [3687 CR 405W, Lake Panasoffkee, FL 33538; case 2026-CC-000358] Sumter County, Florida, is pursuing a foreclosure action against multiple defendants for a property located at 3687 CR 405W, Lake Panasoffkee, FL 33538. The county has a lien due to code enforcement violations including failure to obtain permits, accumulation of trash and debris, inoperable vehicles, and overgrown grass. Defaults have been entered against most defendants due to failure to respond. The county is seeking a Final Default Judgment. [1464 SW 69th Road, Bushnell, Florida 33513; case 2025-CA-000312] Sumter County, Florida, is a subordinate lienholder in a foreclosure case initiated by Wells Fargo Bank. The county is seeking to disburse surplus funds from the foreclosure sale to satisfy its SHIP Loan. The property was located at 1464 SW 69th Road, Bushnell, Florida 33513. The surplus funds amount to $25,781.33, and the county claims $13,775.27 for unpaid principal, late fees, interest, and attorney's fees. [case *ZON26-000007] Rezoning of 7.5 acres from Rural Residential Minimum Five (5) Acres with Conventional Housing (RR5C) to Rural Residential Minimum Five (5) Acres with Optional Housing (RR5) to permit the placement of one (1) Class B Mobile Home. The property is vested for residential development outside the Urban Development Area (UDA). [C17-014; case *S2021-0007] Revocation of a Special Use Permit that allows a sixty (60) seat church on Parcel C17-014. The church currently operates under this permit and has an amended and restated minor Special Use Permit for a graveyard and playground. [7854 SR 471 / N24-042] The Board of County Commissioners expressed consensus to pursue the purchase of parcel N24-042 for integration with the fairgrounds. [5497 Marsh Bend Trail, The Villages, FL 32163] The Board of County Commissioners approved setting a Public Hearing for May 12, 2026, at 6:00 PM at the Everglades Recreation Center, 5497 Marsh Bend Trail, The Villages, FL 32163, to adopt an ordinance establishing the Tourist Development Council and advertise for applications. [948 CR 461, Lake Panasoffkee, FL 33538] The Board of County Commissioners approved accepting the offer from Wayne Cassity for surplus parcel J04E006. [case Ordinance 2026-05] The Board of County Commissioners adopted Ordinance 2026-05, creating a Tourist Development Council, establishing membership criteria, and directing the Council to undertake necessary actions with intent to enact an ordinance levying and imposing a Tourist Development Tax. Public comments were received from Caroline Campbell and Michael Barber. [215 Gloria Rowe Hayward Way, Sumterville, FL 33585] Sumter County Board of County Commissioners (BOCC) approved the methodology for levying non-ad valorem assessments for fire protection and rescue services. This action is based on an Accenture Study dated May 2026. A public hearing is set for July 28, 2026, at 215 Gloria Rowe Hayward Way, Sumterville, FL 33585, to adopt the final resolution. The new methodology will establish a maximum hazardous class funding rate of 35% at $237.88 per fire protection unit, and a hazardous class funding rate of 25% at $169.91 per fire protection unit. These rates are expected to result in lower assessments for a significant percentage of Class 7 residential properties under certain square footage thresholds compared to current rates. The BOCC also approved several other contracts and agreements, including a State Funded Grant Agreement with the Florida Department of Transportation for The Villages Community Resurfacing, and accepted a right-of-way deed from The Villages Land Company, LLC for McNeil Drive Phase 5. All these items were recommended for approval by staff and passed unanimously. [7375 Powell Road, Wildwood, FL 34785 (County Administrator's Office for inspection of records)] This document details the establishment and collection of Fire Protection Assessments for Fiscal Year 2026-2027 in Sumter County, Florida. The assessments will fund fire protection services, facilities, and programs. The proposed rate is $169.91 per Net Fire Protection Unit, with a maximum future rate of $237.88 per Net Fire Protection Unit. Exemptions are provided for government property (with exceptions for federal mortgage entities), institutional property wholly exempt from ad valorem taxation, and agricultural land. Mobile home parks and recreational vehicle parks can receive vacancy adjustments. Property owners can apply for a Fire Flow Mitigation Credit of up to 40% for buildings equipped with certified fire sprinkler systems, certified fire suppression systems, or unique fire-resistant construction. A public hearing is scheduled for July 28, 2026, at the Gloria Rowe Hayward Sumter County Service Center to receive public comments. Notices will be published and mailed by July 7, 2026. The assessments will be collected on the annual ad valorem tax bill. This document is a Fire Assessment Memorandum for Sumter County, Florida, developed by Accenture Infrastructure and Capital Projects, LLC. It details the methodology for calculating fire assessment rates for Fiscal Year 2026-27, focusing on the special benefit fire services provide to properties. The document outlines the service delivery of the Sumter County Fire and EMS Department, including its nine stations, apparatus, and response protocols. It also explains the apportionment methodology, distinguishing between fire suppression and emergency medical services (EMS) costs, as EMS beyond first response is not considered to confer a special benefit to property per Florida case law. The memorandum provides detailed calculations for fire protection units based on hazard class, building square footage, and construction type, along with potential mitigation credits for buildings with fire suppression systems or advanced fire-resistant construction. It includes tables of assessment rates for various property types and sizes, and projected revenues. The document aims to ensure the fire assessment program is legally defensible and adequately funds fire rescue services. This document details the methodology for calculating fire services assessments in Sumter County, Florida. It outlines the administrative and operational factors used to allocate costs, the calculation of assessable expenditures for Fiscal Years 2025-26 through 2029-30, and the apportionment methodology based on Fire Protection Units. The Fire Protection Units are determined by building hazard class and square footage, referencing NFPA standards. The document also discusses credits for fire safety measures, exemptions for governmental and institutional properties, and outstanding issues related to assessment collection and credits. The maximum allowable annual rate per Fire Protection Unit for Fiscal Year 2026-27 is calculated at $679.66, based on total assessable costs of $21,356,763 and 31,422.91 factored Fire Protection Units after credits. This document is a collection of appendices and legal memoranda related to fire protection assessments and county boards. It details fire protection unit assignments based on square footage and hazard classifications, legal justifications for special assessments for fire services, and information regarding vacancies on the Construction Industry Licensing/Fire Code Board of Appeals and the Industrial Development Authority. It does not contain specific project details for contractors. Sumter County Board of County Commissioners is seeking to fill two vacancies on the Library Technology Advisory Board. The board formulates recommendations for improving technology services for the county-wide library system. The meeting type is Regular Meeting, scheduled for 5/26/2026. There is no contract associated with this item, and the budget impact is none. Sumter County Board of County Commissioners is addressing six vacancies on the Public Safety Coordinating Council. This council assesses the population status of detention/correctional facilities and formulates recommendations for improvements. The meeting type is Regular Meeting, scheduled for 5/26/2026. There is no contract associated with this item, and the budget impact is not stated. Sumter County Board of County Commissioners is seeking to fill two vacancies on the Tourist Development Council. The council's purpose is to prepare and submit a plan for tourist development, including proposed uses of tourist development tax revenue. The meeting type is Regular Meeting, scheduled for 5/26/2026. There is no contract associated with this item, and the budget impact is N/A. [case A-15] Sumter County Board of County Commissioners is considering Budget Amendment A-15 for FY 2025/2026. This amendment includes adjustments for Strategic and Marketing Plans, Landscaping and Janitorial Services for the New Service Center & Fire Training/Shelter Building, refund of prior year Payment in Lieu of Taxes, and contribution to the City of Bushnell for Air Quality Analysis. It also amends the budget for retainage for the Supervisor of Elections Warehouse. Staff recommends approval. The meeting date is 5/26/2026. Sumter County Board of County Commissioners is reviewing an Open Requisitions Report for FY 2025/2026, with purchase requests of $25,000 and over requiring approval. Items include Motorola Rave Software Renewal ($41,300.00), Motorola Mach/P1 Integration ($188,938.89), Motorola 10GB Upgrade ($97,395.00), DocuSign Implementation ($32,906.26), Priority Dispatch Licenses ($25,020.00), CityWorks Software Renewal ($72,809.10), Retrofitting (25) I-CON Stainless Steel Combo Units in the Detention Center ($101,063.00), Task Order #1 - 2026 Countywide Pavement Maintenance and Rehabilitation Continuing Services ($1,121,225.39), Task Order #2 - 2026 Countywide Pavement Maintenance and Rehabilitation Continuing Services ($5,213,444.28), Fire Training Center Propane Install for Burn Props ($47,861.00), and Economic Development Marketing Services - Strategic Plan ($21,667.00) and Marketing Plan ($13,333.00). Staff recommends approval. The meeting date is 5/26/2026. [7375 Powell Road, Wildwood, Florida 34785 (County); 641 SW 13th Street, Ocala, FL 34471 (Vendor); case RFP 021-0-2025/JV] Sumter County Board of County Commissioners is considering Amendment #1 to the Agreement with Brightview Landscape Services, Inc. for Sumter County Mowing and Landscape Maintenance Services (RFP 021-0-2025/JV). The amendment adds the Gloria Rowe Hayward Service Center to the existing agreement. The budget impact is $22,640.00 for the remainder of FY 25/26. Staff recommends approval. The meeting date is 5/26/2026. [case ITB # 007-0-2025/JV] Sumter County Board of County Commissioners is considering Change Order #2 to ITB # 007-0-2025/JV with Garcia Civil Contractors LLC for the C 44A and CR 213 Sidewalk Project. The change order includes a quantity overrun for Type A Barbed Wire Fence (15 LF at $306.00) and SOD (2,310 SY at $16,031.10) to prevent washout behind the retaining wall. An additional 58 days will be added to the project duration. The total budget impact is an increase of $16,337.10, bringing the total contract price to $1,574,484.26. Staff recommends approval. The meeting date is 5/26/2026. [7375 Powell Road, Wildwood, Florida 34785 (County); 13052 US Hwy 11, Springville, Alabama 35146 (Vendor); case RFP 038-0-2022/JV] Sumter County Board of County Commissioners is considering Amendment #3 to the Agreement with Southern Cleaning Service, Inc. for Sumter County Janitorial Services (RFP 038-0-2022/JV). The amendment adds the Gloria Rowe Hayward Service Center and the Training/Shelter Facility to the existing agreement. The budget impact is $22,875.00 for the remainder of FY 25/26. Staff recommends approval. The meeting date is 5/26/2026. [4722 Central Pkwy., Sumterville, FL. 33585 (Gloria Rowe Hayward Service Center and Training Center); 7375 Powell Road, Wildwood, Florida 34785 (Sumter County Board of County Commissioners); 3031 N. Rocky Pointe Drive West, Suite 730, Tampa, Florida 33607 (USA Services of Florida, LLC); 8470 NE 44 Drive, Suite B, Wildwood, Florida 34785 (GSB Construction & Development, Inc.); PO BOX 1858, Largo FL 33779 (Turtle Infrastructure Partners, LLC); Center Hill, Florida; Webster, Florida; 7361 Powell Road, Wildwood, FL 34785 (Sheriff's Office); 7375 Powell Road, Wildwood, Florida 34785 (Sumter County Board of County Commissioners); Largo, Florida (Ajax Building Company); case ITB 028-0-2023/JV; RFP 016-0-2023/JV; Purchase Order No. 9128502] This document details several agreements and change orders for Sumter County. It includes a janitorial services contract for the Gloria Rowe Hayward Service Center and Training Center with Southern Cleaning Service Inc., an extension and amendment to the street sweeping contract with USA Services of Florida, LLC, an extension to the on-call general contractor agreement with GSB Construction & Development, Inc. (including a fee schedule for various trades), a change order for guardrail replacement services with Turtle Infrastructure Partners, LLC, interlocal agreements for law enforcement services with the City of Center Hill and the City of Webster, and a change order for the Sumter County Sheriff's Office Training Facility final phase with Ajax Building Company, which deducts owner-purchased materials and equipment from the contract price. [545 CR 482 S., Lake Panasoffkee, FL 33538] Change Order #2 for the Sheriff's Training Facility Final Phase project in Lake Panasoffkee, FL, resulted in a deductive change of $397,705.71, reducing the total contract cost to $6,098,197.29. The contract time was extended by 25 days, with a new final completion date of 05/25/2026. This change order reconciles Owner Direct Purchases (ODP). Change Order #3 for the Sheriff's Training Facility Final Phase project in Lake Panasoffkee, FL, extends the contract duration by 12 days, revising the substantial completion date to 05/06/2026 and the final completion date to 06/05/2026. The contract amount remained unchanged at $6,098,197.29. This change order addresses delays in project completion. [Sumterville, FL] Change Order #4 for the Gloria Rowe Hayward Sumter County Service Center, Fire Training/Hurricane Building, Recovery Building, and other Structures project in Sumterville, FL, increases the contract value by $66,222.34, bringing the total contract cost to $30,022,049.50. The contract time remains unchanged with a final completion date of 05/25/2026. This change order reconciles Owner Direct Purchases (ODP) and tax savings. [Sumterville, FL] Change Order #5 for the Gloria Rowe Hayward Sumter County Service Center, Fire Training/Hurricane Shelter, Fire Recovery Building, and other Structures project in Sumterville, FL, extends the contract duration by 23 days, revising the substantial completion date to 05/18/2026 and the final completion date to 06/17/2026. The contract amount remains unchanged at $30,022,049.50. This change order addresses delays in project completion. [Near US 301 and Central Parkway, Sumter County, FL; case 01135881] A perpetual non-exclusive utility easement was granted to Duke Energy Florida, LLC, for electric and communication lines on property near US 301 and Central Parkway in Sumter County, FL. This easement is necessary for the platting of the property at the new Service Center. The consideration for the easement was $1.00. The easement area is a strip of land ten feet in uniform width. [Not stated, but references County Road C470E right-of-way.] This document details two easements, Easement "A" and Easement "B", located within Section 12, Township 20 South, Range 22 East in Sumter County, Florida. Easement "A" encompasses 0.266 acres and is situated on the north line of the South 1/2 of the Southeast 1/4 of Section 12. Easement "B" covers 0.415 acres and is located in the Southeast 1/4 of Section 12, adjacent to the north right-of-way line of County Road C470E. The document provides detailed metes and bounds descriptions for both easements, along with parcel numbers and references to official records books and pages. No specific applicant, case number, decision, or key dates are mentioned, as this appears to be a legal description for survey and record purposes.
- Board:
- Board of County Commissioners Regular Meeting
- Date:
- 2026-05-26
- Type:
- Packet
- Decision:
- Planning and Zoning Special Master and Staff Recommends Approval. Board of County Commissioners meeting scheduled for May 26, 2026.
- Address:
- 6075 C-575
- Applicant:
- Mary Holcomb
May 19, 2026 Workshop Agenda
This document is a workshop agenda for the Board of Sumter County Commissioners meeting on May 19, 2026, at 6:00 PM. The agenda includes items such as a Public Forum, a discussion on Sumter County Fire and EMS Operational Deployment and Response Times, and a review of the Accenture Fire Assessment Program. The meeting will be held at 7375 Powell Road, Wildwood, FL 34785. No decisions or specific project details beyond the agenda items are mentioned.
- Board:
- Board of County Commissioners Workshop
- Date:
- 2026-05-19
- Type:
- Agenda
- Address:
- 7375 Powell Road, Wildwood, FL 34785
May 19, 2026 Workshop Agenda packet 2026-05-19
Sumter County Fire and EMS Department is holding a workshop on May 19, 2026, at 6:00 PM, located at 7375 Powell Road, Wildwood, FL 34785. The workshop agenda includes a Public Forum, a discussion on Sumter County Fire and EMS Operational Deployment and Response Times, an Accenture Fire Assessment Program review, and Board Dialogue. Documents related to the Fire and EMS Operational Deployment and Response Times and the Accenture Fire Assessment Program are available.
- Board:
- Board of County Commissioners Workshop
- Date:
- 2026-05-19
- Type:
- Packet
- Address:
- 7375 Powell Road, Wildwood, FL 34785
May 18, 2026 Planning and Zoning Special Master Meeting Agenda
This document is an agenda for the Sumter County Planning and Zoning Special Master meeting on May 18, 2026. It lists several items for approval and discussion, including minutes from a previous meeting and applications for zoning changes. The meeting will be held at the Everglades Recreation Center, 5497 Marsh Bend Trail, The Villages, FL 32163. The agenda includes three specific cases: STU26-000020 for Chase Animal Rescue and Sanctuary Inc. and Nina Plail, STU26-000024 for Leed, and ZON26-000015 for Sumter County. Documents related to each case, such as staff reports, applications, proof of publication, and public input, are listed.
- Board:
- Planning and Zoning Special Master (PZSM)
- Date:
- 2026-05-18
- Type:
- Agenda
- Address:
- 5497 Marsh Bend Trail, The Villages, FL 32163
- Applicant:
- Chase Animal Rescue and Sanctuary Inc. and Nina Plail, Leed, Sumter County
May 18, 2026 Planning and Zoning Special Master Meeting Agenda packet 2026-05-18
[6209 SE 122ND BLVD WEBSTER FL 33597; case STU26-000020] Sumter County Planning and Zoning Special Master approved a Minor Special Use Permit for an exotic wildlife rescue and sanctuary. The permit is for Chase Animal Rescue and Sanctuary Inc. and Nina Plail on parcels T15-006 and T15-008. The property is 10.00 acres MOL, located south of CR 707 and east of CR 711 in the Webster area. The existing zoning is General Agriculture Minimum Ten Acres with Conventional Housing (A10C), and the future land use is Agriculture. The use allows for keeping, rehabilitating, and entertaining the public with non-farm and exotic animals on an appointment-only basis. The approval is subject to several conditions, including that the permit is specific to the current landowners and requires a new permit for any transfer of property or significant change in ownership of the entity. Further development requires site and building permitting processes, and county personnel will have site access for monitoring. Suspension or revocation of other county permits will result in the suspension or revocation of this permit. Casey Chapman submitted written comments requesting denial, citing concerns about website advertising including 'Experience Packages' and deed restrictions for 'Country Oaks'. [8885 CR 622C BUSHNELL FL 33513; case STU26-000024] Sumter County Planning and Zoning Special Master approved a renewal of a construction temporary use permit for Lacy Leed on parcel M18A200. The permit allows a Recreational Vehicle (RV) to remain on the property for one year as a construction residence while a primary dwelling is built. The property is 0.204 acres MOL, located south of CR 622C and west of C-575 in the Bushnell area. The existing zoning is Urban Residential Minimum One-Sixth Acre with Mobile Home Housing (R6M), and the future land use is Rural Residential. The RV is connected to well and septic. The permit is concurrent with building permit #BD25-002711 and expires on May 18, 2027, or upon issuance of a certificate of occupancy for the new residence. The RV must be removed within 30 days of permit expiration or certificate of occupancy. No public comment was noted. [case ZON26-000015] Sumter County Planning and Zoning Special Master reviewed a Land Development Code (LDC) Amendment requested by Sumter County. The amendment aims to fix errors in the LDC identified since the July 22, 2025 update, addressing redundancy and conflicts with the Comprehensive Plan. The proposed changes involve deleting and replacing certain divisions within the LDC. The Business Impact Estimate indicated no direct economic impact on businesses, no new charges or fees, and no direct economic impact on businesses. The Planning Division Staff recommended APPROVAL. The Board of County Commissioners is scheduled to review this on June 9, 2026. [case Ordinance 2026-______] Sumter County Board of County Commissioners approved an ordinance amending Chapter 13 of the Sumter County Code of Ordinances, specifically the Land Development Code. Key changes include: 1) Requiring conceptual plans for Conservation Subdivisions to show features within 500 feet of the site, including floodplains and greenways, and ensuring the conceptual plan does not extend onto neighboring properties. 2) Classifying density for Conservation Subdivisions at one dwelling unit per three gross acres across the entire subject property. 3) Requiring a Special Use Permit for sewage treatment plant effluent disposal (sludge) in the Industrial (ID) Zoning District. 4) Correcting 'Assisted Living Facility, large' to 'Assisted Living Facility' in the Schedule of Uses. The Local Planning Agency recommended approval on May 18, 2026, and the Board of County Commissioners approved the amendment on June 9, 2026. Public comment was considered during hearings.
- Board:
- Planning and Zoning Special Master (PZSM)
- Date:
- 2026-05-18
- Type:
- Packet
- Decision:
- Approved
- Address:
- 6209 SE 122ND BLVD WEBSTER FL 33597
- Applicant:
- Chase Animal Rescue and Sanctuary Inc. and Nina Plail
May 12, 2026 Regular Meeting Agenda
This document is an agenda for the Board of Sumter County Commissioners meeting on May 12, 2026. It outlines various items including public hearings, reports, new business, appointments, financial matters, contracts, and general items for consideration. Several items involve potential work for contractors and trades, such as a public hearing to adopt an ordinance creating a Tourist Development Council and levying a tourist development tax, various proclamations, presentations, letters regarding services and projects, and contract agreements for affordable housing programs, storm pipe replacement, rights of way mowing, data sharing, and community resurfacing. There are also items related to property ownership and maintenance, position revisions, and grant applications.
- Board:
- Board of County Commissioners Regular Meeting
- Date:
- 2026-05-12
- Type:
- Agenda
May 12, 2026 Regular Meeting Agenda packet 2026-05-12
[7375 Powell Road, Wildwood, FL 34785 (County Administrator's Office); 5497 Marsh Bend Trail, Grand Canyon Room, The Villages, FL 32163 (Meeting Location); case Ordinance 26-] The Sumter County Board of County Commissioners held a meeting on May 12, 2026. A key agenda item was a public hearing to adopt an ordinance creating a Tourist Development Council and establishing criteria for levying a Tourist Development Tax. Staff recommended approval. The ordinance aims to re-establish a tourist development tax, which was repealed in 2020. The proposed Tourist Development Council will consist of nine members and will be responsible for preparing a plan for tourist development and recommending uses for tax revenue. The meeting also included several proclamations recognizing various weeks and months, and informational items regarding contracts, legal cases, and financial matters. Additionally, the board considered appointments to various committees and reviewed meeting minutes. The City of Bushnell Council agreed to proceed with air quality analysis after Compost USA vacates the ACMS property. This analysis is to be conducted by Arcadis. Sumter County will contribute $10,000 to the City of Bushnell for this task. The work is planned to commence after Compost USA departs the HOF property. The City of Bushnell formally expressed opposition to a deep injection well associated with the Heart of Florida Landfill in Sumter County, citing concerns about potential implications for underground drinking water sources and long-term reliability. They requested FDEP to evaluate alternative approaches and provide more transparency. Sumter County also expressed concerns about the injection well and requested FDEP to host a public education session. Sumter County inquired with SWFWMD about potential ground vibrations and residential well impacts, with SWFWMD stating that vibration issues are handled by FDEP. A separate project involves RND Anaerobic Digestion, a $100 million investment to convert food waste and biosolids into Renewable Natural Gas, creating 75-120 construction jobs and 13-17 permanent jobs. This project is expected to reduce odor, lower greenhouse gas emissions, and avoid approximately 45,200 metric tons of CO2 annually. TECO has a contract to purchase the gas. RND will pay a $2.5 million reservation fee for future wastewater and water needs. This document contains a list of completed and issued well construction permits in Sumter County. It also includes correspondence regarding complaints of ground shaking and well collapse near the Heart of Florida Landfill, and details a Public Transportation Grant Agreement between the Florida Department of Transportation and Sumter County Board of County Commissioners. [Wildwood, FL] This document is a Public Transportation Grant Agreement between the State of Florida Department of Transportation and Sumter County Board of County Commissioners, Sumter County Transit. The agreement provides FTA Section 5310, FFY25/SFY26 capital funds for the purchase of up to six (6) bus replacements under 30 feet in length. The total financial assistance awarded is $688,994.00, with $551,195.00 in Federal funds, $68,900.00 in State funds, and $68,899.00 in Local funds. The project is located in Wildwood, FL, Sumter County. The agreement outlines various requirements for the Agency, including procurement procedures, reporting, compliance with federal and state laws, and maintenance obligations. It also details conditions for contractors and subcontractors, such as Disadvantaged Business Enterprise (DBE) policies, E-Verify requirements, and insurance provisions. The agreement specifies that the Agency is responsible for all future maintenance costs after project completion. The total project cost is estimated at $688,994.00, with the majority allocated to Capital Equipment. The agreement is effective for the State Fiscal Year 2026. [case 456117-2-94-25] Sumter County Board of County Commissioners (Sumter County Transit) received FTA Section 5310 funds for a capital purchase. The award amount is $551,195. The financial project number is 456117-2-94-25. The contract type is Grant Disbursement (Grant) with an amount of $620,094.00. The agreement begins on 04/29/2026 and ends on 03/26/2028. The method of procurement is Exemption (287.057). [State Road 35 (U.S. 301) from County Road 470 to County Road 525E; case 4301322] The Florida Department of Transportation (FDOT) is amending the Work Program for Project 4301322, concerning State Road 35 (U.S. 301) from County Road 470 to County Road 525E in Sumter County. The construction is deferred due to a procurement method change, delaying the project until right-of-way certification is received. The project involves adding lanes and reconstruction. The total budgeted amount for this project across various phases and funding sources is approximately $62,297,173 for 2026 and $62,236,691 for 2027, with specific amounts for construction, utility, and support consultant/contractor phases. SECO Energy is clarifying its role in roadway lighting account transfers to Sumter County, which occurred between 2019 and 2025. These transfers were administrative, facilitating accounts from developers/entities to the County, which assumed responsibility for certain roadway lighting as part of an agreement. SECO Energy states no Area Lighting agreement exists between them and Sumter County; the lights are provided under SECO's approved rate tariff. The transition from High Pressure Sodium (HPS) to LED lighting is a system-wide conversion, with HPS fixtures discontinued in December 2025. SECO will continue to work with Sumter County on lighting matters, with the County as the member of record. This document is a tariff detailing various rate schedules for electric service provided by SECO Energy. It outlines charges, applicability, and conditions for different customer types, including General Service (GS), General Service/Demand (GSD), General Service/Demand Interruptible (GSDI), Large General Service/Demand (LGSD), Residential Service (RS), Residential Service Time-Of-Use (RS-TOU), Public Charging for Electric Vehicles (EV), Residential Load Management, Lighting Service (LS), Contract Service Agreement (CSA), Wholesale Power Cost Adjustment (PCA), Line Extension Charges, Net Metering, and Interconnection Agreements. Specific details on daily customer charges, energy charges per kWh, and demand charges per kW are provided for commercial and industrial rates. Residential rates include daily customer charges and tiered energy charges. The document also details various fees for services such as late payments, reconnections, new service connections, and opt-outs from automated metering. It specifies terms for line extensions, including Contributions In Aid of Construction (CIAC) calculations, and outlines the net metering policy for customer-owned renewable generation systems up to 1,000 kW. Interconnection agreements for member-owned renewable generation systems are also detailed, requiring adherence to specific standards and local codes. The document includes effective dates for revised sheets, typically ranging from 2007 to 2025, and is issued by Curtis Wynn, CEO, or James P. Duncan, CEO & General Manager. [M21 -022; case SD26-000013] Sumter County Board of County Commissioners is reviewing a fee waiver request for Site Development Plan permit #SD26-000013 for the second expansion of the Gulf Coast & Central Florida Railroad Museum, Inc. The expansion will house the museum's Tarpon Springs display. The permit application is currently under review by Planning, Public Works, and Fire departments. A first comment letter is expected to be sent to the applicant on May 15, 2026. [9060 County Road 231, Wildwood, FL 34785; case STU26-000025] Sumter County Board of County Commissioners is reviewing a fee waiver request for Special Exception Use permit #STU26-000025 for the Young Performing Artists, Inc. The permit is for the 2026 Mr. & Miss Royal King & Queen Competition, scheduled for June 20, 2026, from 10 am to 3 pm, with an expected attendance of 50-75 people. Planning, Public Works, and Fire departments have reviewed and approved the application. A Settlement Agreement and General Release between Sumter County ('Client') and Kimley-Horn and Associates, Inc. ('Kimley-Horn') regarding the Supervisor of Elections Facility project. Kimley-Horn will pay $11,830.00 to Mark Cook Builders, Inc. to settle disputes related to Kimley-Horn's services on the project. The agreement releases Kimley-Horn from all claims related to the project. [case 2026-CA-000207] Sumter County Board of County Commissioners is a defendant in a mortgage foreclosure case. The County claims an interest in the property via a Claim of Lien recorded on January 30, 2026, in Official Records Book 5403, Page 275. The County asserts its lien is subordinate to the mortgage but superior to other defendants' interests. The County also notes the property is out of compliance with Sumter County Code of Ordinances and that a prospective purchaser will be expected to bring it into compliance. [11826 NE 62nd Terrace, Lady Lake, FL 32162; case 25-012141] Sumter County, Florida, is pursuing a code enforcement lien against TPC Villages LLC for expired SPAL and permits. The property is located at 11826 NE 62nd Terrace, Lady Lake, FL 32162. As of April 24, 2026, the total amount owed for the lien, including daily fines and administrative costs, is $21,461.04. The daily fine of $100/day is still accruing as the property remains out of compliance. The case number associated with this lien is 25-012141. [2079 Switch Grass Circle, Ocoee, FL 34761; case 2026-CC-000358] Sumter County, Florida, is seeking a judicial default against Eugenia F. Hitson and The Unknown Spouse of Eugenia F. Hitson in a foreclosure case. The property in question is located at 2079 Switch Grass Circle, Ocoee, FL 34761. The County filed its Complaint for Foreclosure on February 16, 2026. Attempts to serve the defendants were unsuccessful, leading to service by publication. The deadline for an answer was April 27, 2026, and no response was filed. The case number is 2026-CC-000358. [case 2026-CC-000358] Sumter County, Florida, is seeking a judicial default against Certain Capital Investments LLC and Certain Capital Investments LLC FBO Firstrust in a foreclosure case. The property address is not explicitly stated in this document, but it is related to a foreclosure action. The County filed its Complaint for Foreclosure on February 16, 2026. Service was completed on February 24, 2026. The deadline for an answer was March 16, 2026, and no response was filed, leading to a Clerk's Default on March 26, 2026. The case number is 2026-CC-000358. [3687 CR 405DW, Lake Panasoffkee, FL 33538; case 2026-CC-000358] Sumter County, Florida, is seeking a judicial default against The Estate of Charlene R. Garris, The Unknown Spouse of Charlene R. Garris, Delores Lovett Smith, Mathew S. Smith, Richard Lee Zinsmeister, and The Unknown Tenant or Tenants in Possession in a foreclosure case. The property address is 3687 CR 405DW, Lake Panasoffkee, FL 33538. The County filed its Complaint for Foreclosure on February 16, 2026. Service attempts were made between February 27, 2026, and March 4, 2026, but were unsuccessful, leading to service by publication. Deadlines for answers were April 13, 2026 (for the Estate) and April 9, 2026 (for others). No responses were filed. The case number is 2026-CC-000358. [301.2400538.010; case 3-0187870] Payment to DRMP, INC. for Courthouse Remodel, Project 3-0187870. Payment to Brightview Landscapes, LLC for Road Mowing Services. Payment to Air Mechanical & Service Corp for various HVAC services across Sumter County facilities, including actuator installation, sensor replacement, unit inspection, heater replacement, ice machine relocation, and monthly/quarterly maintenance. [case 50000341014] Payment to Ajax Building Corporation for Sheriff Training Facility, Final #8. [case 24-008.08] Payment to Infrastructure Consulting & Engineering for project 24-008.08, specifically related to US 301-C466 Building. [case BOSCC 1253, J04E006 1254] Payments to GSB Construction and Development Inc for Dumpster Gate Repair at BOSCC and Demo & Clean-Up at J04E006. [case 50000295031] Payment to Ajax Building Corporation for Smtrvle SCSC & Fire Train #19. Payment to C.W. Roberts Contracting, Inc for Hot Mix Asphalt, ODP Asphalt, and SC C466 @ C475N Roundabout #7. [case 142109218, 142109202.1] Payments to Kimley-Horn and Assoc, Inc for Central Parkway Widen project (142109218) and CR 48 Lap (142109202.1). Payments to Glen Holt Aluminum LLC for Demo/Recon at Applegate #2, Berry #2, and Martinez #2. [case ITB00702025-PAYAPP10] Payment to Garcia Civil Contractors LLC for C44A & CR213 Sidewalk Improvement #10. [case 3918-4] Payment to Glen Holt Aluminum LLC for Ship Demo/Recon Green #4. Payment to M C Dean Inc for Lake Pan Library sign lights, main breaker at fairgrounds, and desk receptacle/light pole at ground boat. [Sumter; case P707000123] Payments to Vectrus Systems LLC for E-911 GIS Services in Sumter. Payment to JDMF LLC for Rights of Way Mowing and Litter services. [case BOSCC 1250] Payment to GSB Construction and Development Inc for Gas Heater Pipe services at BOSCC. Payment to Air Mechanical & Service Corp for various HVAC services across Sumter County facilities, including refrigerant work, heater installation, walk-in cooler repair, TXV valve replacement, freon/puron supply, and monthly/quarterly maintenance. [case 1035665548] Payments to Motorola Solutions, Inc for Security System Install and Motorola Active-eye. [case INV005413] Payment to Library Systems & Services, LLC for Library Systems & Services for March. [case 1150741] Payments to Transdev Fleet Services Inc for Fleet - Monthly Admin and Labor Costs/Parts. [case CC4451-001.01] Payment to Accenture LLP for MSBU Study & Services. [C466 @ C475N ROUNDABOUT #8; case 1512282-PAYAPP8] Payment to C.W. Roberts Contracting, Inc. for Hot Mix Asphalt and a Roundabout project. Payments were made for specific invoice items related to asphalt and roundabout construction. No decision or zoning change information is present. [C470 EXT PES] Payment to Kimley-Horn and Associates, Inc. for engineering services related to C470 Extension Project (PES) and SS4A Plan. Payments are for specific project phases and plans. No decision or zoning change information is present. [C466@US301; case 24-008.09] Payment to Infrastructure Consulting & Engineering for final design services related to C466 @ US301. No decision or zoning change information is present. Payment to Brightview Landscapes, LLC for landscape contract services. No specific project location, size, zoning change, or decision is stated. [VAR LOC SUMTERCO] Payment to Air Mechanical & Service Corp for ice machine maintenance and monthly maintenance services at various Sumter County locations. No specific project details or decisions are stated. [FDORM, NEW JAIL, JUD BLDG, DET CTR, CRTHSE] Payment to A Generator Guy for fuel tank inspection and testing, and minor preventative maintenance at various county facilities including FDORM, New Jail, Jud Bldg, Det Ctr, and Crthse. No specific project details or decisions are stated. [PK ST#30] Payment to M C Dean Inc for removal and replacement of a wall at Park Street #30. No specific project details or decisions are stated. Payment to Pestmaster Services of the Villages for pest control services at an unspecified location. No specific project details or decisions are stated. Payment to Stewart and Stevenson FDDA LLC for an ODP Generator Package. No specific project location, size, zoning change, or decision is stated. [SUMTER] Payment to Traffic Engineering and Management LLC for enhanced highway signage in Sumter County. No specific project details or decisions are stated. [SR 44&C 47 #9] Payment to DRMP, Inc. for rehabilitation payments and work on SR 44 & C 47 #9. No specific project size, zoning change, or decision is stated. Payment to Unhinged LLC for breaching windows and doors. No specific project location, size, zoning change, or decision is stated. Payment to Kofile Technologies Inc for scanning of large site plans. No specific project location, size, zoning change, or decision is stated. Payment to Concept Seating Government LLC for emergency communication E-911 chairs. No specific project location, size, zoning change, or decision is stated. Payment to InteriorMark LLC DBA Theater Seat Store for a recliner for Station. No specific project location, size, zoning change, or decision is stated. [case CS1603923] Payment to Finalcover LLC for CaseGuard Ult Suite. No specific project location, size, zoning change, or decision is stated. [PARCEL J04E006] Payments to Leisure Time Mobile Home Estates Property for annual maintenance on Parcel J04E006 and a lien on the same parcel. No specific project details or decisions are stated. [PARCEL J04E006] Payment to Suncoast Credit Union for a loan payoff related to Parcel J04E006. No specific project details or decisions are stated. [JAIL, BHD] Payment to RCM Utilities LLC for repairs to a Rinai water heater at the jail and for snake services for toilets at BHD. No specific project details or decisions are stated. Payment to Boehringer Ingelheim Animal Health USA Inc for medical supplies. No specific project location, size, zoning change, or decision is stated. Payment to Otis Elevator Company for an elevator contract. No specific project location, size, zoning change, or decision is stated. [SOE] Payment to Sumter Painting and Solutions LLC for removal of lettering and pressure washing at SOE. No specific project size, zoning change, or decision is stated. Payment to Idexx Distribution Inc for veterinary diagnostic testing. No specific project location, size, zoning change, or decision is stated. Payment to Doodie Calls Inc for portable toilet rental. No specific project location, size, zoning change, or decision is stated. Payment to Paul Brishke for Operative IQ Conference services. No specific project location, size, zoning change, or decision is stated. [SUMTERBOCC] Payment to AssuredPartners of Florida LLC for benefit consulting services for Sumter County BOCC. No specific project details or decisions are stated. Payment to Daniel Enrique Vazquez for reimbursement for protective footwear. No specific project location, size, zoning change, or decision is stated. Payment to WCC Business Solutions Inc for monthly contract base services. No specific project location, size, zoning change, or decision is stated. Payment to Level 3 Communications LLC for DIA services. No specific project location, size, zoning change, or decision is stated. Payments to First Citizens Bank and Trust Company for lease charges on various accounts. No specific project location, size, zoning change, or decision is stated. Payment to NDS Wellness LLC for wellness exams for Fire & EMS. No specific project location, size, zoning change, or decision is stated. [ST#31] Payment to M C Dean Inc for a switch for EM Lite at Station #31. No specific project details or decisions are stated. [case AFAA5BB2-0063] Payment to Column Software PBC for Notice of Intent to Claim. No specific project location, size, zoning change, or decision is stated. Payment to Max Machined LLC for overpayment on 3 CitizenServe cases. No specific project details or decisions are stated. Payment to Munz Holdings LLC for two withdrawn permits. No specific project details or decisions are stated. Payment to Baker Distributing Co for HVAC miscellaneous filters. No specific project location, size, zoning change, or decision is stated. [case 26-0084] Payment to Purcell Funeral Home for indigent cremation services. No specific project details or decisions are stated. This document is a payment register from the Sumter Board of Commissioners detailing various payments made on or around April 23, 2026. It lists vendor names, invoice details, and payment amounts. Specific projects or development applications are not detailed, but rather routine operational expenses and vendor payments. This document is a payment register and check/NOD register for Sumter Board of Commissioners, detailing various payments made to vendors and individuals. It does not contain information about specific construction projects, zoning changes, or development proposals. The entries are primarily financial transactions for services, medical supplies, and employee benefits, with a list of individual employee payments. There is no information regarding new construction opportunities, public comments on development, or decisions on development projects. [CR 239, Oxford area] Sumter County Board of County Commissioners approved a through truck traffic restriction on CR 239 in the Oxford area. This restriction is to prevent trucks from using the road to access the Black Kaw facility, as the road is not designed for heavy truck traffic and is connected to CR 237 for access. Staff recommended approval, and the motion carried unanimously. [City of Center Hill Joint Planning Area; case LU26-000007] Sumter County approved a small-scale comprehensive plan amendment to remove 124.55 acres from the Joint Planning Area (JPA) of the City of Center Hill. This modification aligns with adjusted utility service area agreements between Sumter County, the City of Center Hill, and the City of Webster, ensuring parcels are entirely within one jurisdiction. The City of Center Hill had previously approved this modification. Staff and the Planning and Zoning Special Master recommended approval, and the motion carried unanimously. [City of Webster Joint Planning Area; case LU26-000008] Sumter County approved a small-scale comprehensive plan amendment to add 124.55 acres to the Joint Planning Area (JPA) of the City of Webster. This change is coordinated with Sumter County and the City of Center Hill, and aligns with adjusted utility service area agreements to ensure parcels are entirely within one jurisdiction. The City of Webster had previously approved this modification. Staff and the Planning and Zoning Special Master recommended approval, and the motion carried unanimously. [case LU25-000027] Sumter County adopted a large-scale comprehensive plan amendment to change the future land use on 48.56 acres from Agriculture to Rural Residential and on 14 acres to General Commercial. This amendment aims to align current uses and densities with the future land use map for 29 subject parcels that are vested non-conforming. No new development is proposed by this amendment. Staff and the Planning and Zoning Special Master recommended approval, and the motion carried unanimously. [case ZON25-000056] Sumter County approved a rezoning of 14 acres from Light Commercial (CL) and Rural Residential Minimum Five Acres with Conventional Housing (RR5C) to Heavy Commercial (CH). This rezoning addresses split zoning and aligns the parcel with its proposed future land use of General Commercial and existing commercial activity. The site is within the Urban Development Area and an Economic Activity Center. Staff and the Planning and Zoning Special Master recommended approval, and the motion carried unanimously. [case ZON25-000013] The rezoning of 51.6 acres from General Agriculture Minimum 10 Acres with Conventional Housing (A10C) and Rural Residential 5 Acres with Conventional Housing (RR5C) to PUD for Development as a Conservation Subdivision was continued to the April 14, 2026 Board Meeting. No motion or vote was needed. Change Order #1 for the Sumter County Sheriff's Office Final Phase to extend substantial and final completion dates. Staff recommends approval. Change Order #3 for the Gloria Rowe Hayward Sumter County Service Center and Fire Training Center to extend substantial and final completion dates. Staff recommends approval. Memorandum of Understanding between Lake Technical College and Sumter County Board of County Commissioners for Paramedic Education. Staff recommends approval. [US 301 and C 466 Intersection] Task Order #9 with Infrastructure Consulting and Engineering and Sumter County Board of County Commissioners for the design services of US 301 and C 466 Intersection Improvements. Staff recommends approval. Approval of Waiver of Fines and Release of Lien for Amber Hoyme. Staff recommends approval. Approval of Waiver of Fines and Release of Lien for Telzey Ecklin. Staff recommends approval. [case ZON25-000013] Rezoning Case ZON25-000013 for Williams on 51.6 Acres MOL from General Agriculture Minimum 10 Acres with Conventional Housing (A10C) and Rural Residential 5 Acres with Conventional Housing (RR5C) to PUD for Development as a Conservation Subdivision. Planning and Zoning Special Master and Staff Recommend Approval; however, with Different Conditions - Staff Recommends the Conditions Removed by the Planning and Zoning Special Master be Retained. This agenda item is continued to July 14, 2026 at 6:00 p.m. at The Gloria Rowe Hayward Service Center location. New notices will be sent out to the public. [Portion of Plum Street; case SUB26-000005] Public Hearing to Consider the Vacation of a Portion of Plum Street Adjacent to Parcels J13B203 and J13B204. Staff recommends approval. The motion carried unanimously 5-0. Resolution to Appoint Members to the Tourist Development Council. Eight (8) vacancies with applications. Staff recommends approval. The Board of County Commissioners adopted Ordinance 2026-___ creating a Tourist Development Council. The TDC would need to prepare and submit a plan for tourist development. Members of the TDC would be nine members comprised of specific seats and terms. [1336 CR 467D, Lake Panasoffkee, FL 33538] Wayne Cassity, a General Contractor and owner of ABA Constructors Inc., applied for the Tourist Development Board. He is a Sumter County resident and a certified general contractor (CGC1512336). He has experience with rental and commercial real estate properties, marketing, and knowledge of Sumter County areas that could benefit tourism and economic development. He believes his marketing experience can help identify uses for the 40% promotional and 60% capital improvement funds, and he has knowledge of areas with tourism potential outside of The Villages. [3531 CR 714, Center Hill, FL 33514; case Submission #1283521] Stephanie Negrete, owner/operator of Crete & Company, LLC, applied for the Affordable Housing Advisory Committee. She is a Sumter County resident for 4 years and holds an Associate’s Degree in Business Management and a Bachelor’s Degree in Land Surveying/Geomatics. Her background includes land surveying, construction coordination, permitting, and small business operations. She believes her education and work experience in land use, property, construction, and community development, along with her understanding of communication between residents, contractors, and local government, will allow her to contribute a practical, detail-oriented, and community-minded perspective focused on responsible growth, local businesses, and quality of life. [10640 NE 27th Street, Oxford, FL 34484; case Submission #1283472] Gerard J. Lachnicht, a resident of Oxford, FL for 12 years, applied for reappointment to the Industrial Development Authority. He has an MSF in Finance from Florida International University and works in Wealth Management at Hancock Whitney. He has served on the board for several years and believes his finance and business background will add value to the process. [9145 Wildlight Trail, Wildwood, FL 34785; case Submission #1283591] Andrea McHugh, a Sumter County resident for 8 years, applied for the Tourist Development Council. She resides at 9145 Wildlight Trail, Wildwood, FL 34785. She is a Senior Area Sales Manager at Brownwood Hotel and Spa, Waterfront Inn, and Hotel Eastport. She has over 14 years of hospitality experience, including increasing banquet revenue and cross-selling hotel properties. She believes she can contribute a results-driven perspective grounded in The Villages’ unique tourism market, offering data-driven insights on booking trends and guest behavior. She also has experience as General Manager for Blackjack Sporting Clays in Sumterville. Her key clients include The Villages, Parady Financial, Blackstone Financial Advisory Group, Gresco Utility Supply, Ashgrove, and T&D family of companies. She is willing to file the required financial statement. [1852 Alton Ave., The Villages, FL 32163; case Submission #1283573] Ronald James McMahon, a resident of The Villages, FL for 19 years, applied for the Tourism Advisory Committee. He resides at 1852 Alton Ave., The Villages, FL 32163. He is retired and previously worked as a Manufacturing and Contract Cost Analyst for GE. He previously served on the Tourist Council for approximately 2 years before it was disbanded and has experience in the tourism industry, including managing tourism in Saratoga Springs, NY. He is willing to file the required financial statement. [1828 CR 543B, Sumterville, FL] Dana Martina applied for the Tourist Development Council. She resides at 1828 CR 543B, Sumterville, FL. She is a hospitality professional with experience in areas utilizing a bed tax structure to grow markets and support tourism. She is excited about the re-establishment of a Tourism Council and believes Sumter County is ready to focus on growing its tourism/visitor base. The Construction Industry Licensing/Fire Code Board of Appeals has three vacancies: Architect, Business Person, and General Contractor. The board evaluates and approves/disapproves contractors for local licensing, hears complaints against licensed contractors, disciplines licensed contractors, and hears reports of unlicensed contractor activity. Members must be legal, bona fide residents of Sumter County, and contractors must hold an active Sumter County Competency Card or a Florida Certified License. Terms are three years. The City Commission of Wildwood has appointed Commissioner Fountaine to serve as the Wildwood representative on the Tourist Development Council (TDC). [CR 614A, CR 727, CR 232 (Wildwood), CR 309 (Lake Panasoffkee), Stillwater Trail, and Buena Vista Boulevard; case ITB # 024-0-2025/RS] Sumter County Board of County Commissioners meeting on May 12, 2026, included approval of a change order for the Storm Pipe Replacement Project. The original contract with Bulldog Sitework, LLC was for $334,862.22. Change Order #1 increases the contract by $156,068.74, bringing the total to $490,930.96. The change order addresses deteriorated storm pipes at CR 614A and CR 727, adds two new locations for storm pipe replacement at CR 232 (Wildwood) and CR 309 (Lake Panasoffkee), and revises the scope for Stillwater Trail and Buena Vista Boulevard due to field conditions. [Webster Library; case Budget Amendment A-14 FY 2025/2026] Sumter County Board of County Commissioners meeting on May 12, 2026, included approval of a budget amendment (A-14) for FY 2025/2026. The amendment includes HVAC repairs for Public Safety Buildings, purchase of five new tables for the Webster Library, and monthly monitoring for the A-Line Fire for the new Fire Training Center, funded by the General Fund (001) with a $30,306 impact. It also amends the budget for LAP C466 at C4754 improvements, a decrease for FY26 design of the Resurfacing C48 project (to be completed in FY27), and an increase for FY26 construction for C470 Safety improvements, funded by the Secondary Trust Fund (106) with a $100,000 impact. [3918 Pine Avenue, Coleman, FL 33521] Sumter County Board of County Commissioners meeting on May 12, 2026, addressed the Affordable Housing Program. Ms. Linda Green received $475.00 in grant assistance for demolition/reconstruction of a new home at 3918 Pine Avenue, Coleman, FL 33521, after her previous home was destroyed by fire. The assistance leveraged Affordable Housing funds with SHIP funds. The contract includes provisions for recapture of funds if the property ceases to be owned and occupied by the Grantee or a family member within five years. Sumter County Board of County Commissioners meeting on May 12, 2026, reviewed purchase orders for FY 2025/2026. Four requisitions totaling $242,660.92 were recommended for approval. These include a CAD Software Renewal for $87,860.92 (Vendor: TRITECH SOFTWARE SYSTEMS, G/L: 001-415-525-4607), a RapidDeploy Software Renewal for $67,200.00 (Vendor: RAPIDDEPLOY INC, G/L: 114-155-525-4607), Purchase of Leased Vehicle/Equipment for $25,200.00 (Vendor: ACME AUTO LEASING, LLC, G/L: 001-416-541-6400), and C 48 Wetland Mitigation Credit Purchase for $62,400.00 (Vendor: SOUTHERN STATES LAND AND TIMBE, G/L: 106-340-541-6392). Sumter County Board of County Commissioners meeting on May 12, 2026, addressed the disposal, surplus, and transfer of property. The request was to approve inventory transactions for items deemed out of service or replaced due to age/mileage. Items include two K12 Saws (Fire & EMS) and three Passenger Buses (Fleet). Sumter County Board of County Commissioners meeting on May 12, 2026, reviewed the Sumter County Fire & EMS Collections Bad Debt Write-Off for FY 2025/2026. The total monthly write-off for February 2026 was $163,164.49. This policy allows for the review and write-off of uncollectible debt from EMS transportation billing, which began in October 2022. [case RFP 014-0-2023/JV] Sumter County Board of County Commissioners approved Extension #2 to the contract with JDMF LLC for Rights of Way Mowing and Litter Removal. The extension is from April 25, 2023, to April 24, 2027. The total budget impact for this extension is $687,464.10, funded by the General Fund. This extension adds new roads to the contract, increasing the per-acre mowing cost from $30 to $42 due to narrower right-of-ways (less than 15 feet) and a higher mileage count (325 miles vs. 120 miles). The litter removal cost remains $14 per acre. The total annual cost for mowing and litter removal is projected to increase significantly. [7375 Powell Rd Ste 200 Wildwood, FL 34785 (Sumter County)] Sumter County Board of County Commissioners approved a Beta Analytics and Data Sharing Agreement with Motorola Solutions, Inc. This agreement allows Sumter County to participate in a beta program and data sharing initiative to support integration with PowerDMS and other County systems. Participation is voluntary and may be discontinued at any time. The agreement is a standing agreement for current and future Motorola beta programs and is exempt from public records. There is no budget impact or funding source specified for this agreement. [The Villages Community Resurfacing, District 2; case FPN 447408-1-54-01] Sumter County Board of County Commissioners approved a State Funded Grant Agreement (SFGA) with the Florida Department of Transportation (FDOT) for the construction phase services of The Villages Community Resurfacing project. The SFGA will reimburse project costs up to $2,568,002. The project involves milling and resurfacing on multiple roads in District 2 of The Villages. The total estimated project cost is $4,059,028. The agreement is effective May 12, 2026, and the project completion date is March 31, 2027. [Various streets within The Villages Communities, including San Marino Drive, Enrique Drive, Augustine Drive, Margarita Drive, and a portion of Morven Parkway.; case 447408-1-54-01] This document is a State-Funded Grant Agreement between the State of Florida Department of Transportation and Sumter County for The Villages Community Resurfacing project. The project involves milling and resurfacing of various roads within The Villages Communities, totaling 11.32 miles. Key activities include reworking of limerock base, pavement markings, and other construction elements like mobilization, maintenance of traffic, and pollution prevention. All pedestrian facilities must adhere to ADA standards. The project is scheduled for construction contract letting by June 29, 2026, with a 90-day construction duration, and completion by November 01, 2026. The total project cost is $4,059,028.00, with $2,568,002.00 in state funds and $1,491,026.00 in local funds. The agreement outlines detailed requirements for contractors, including contract review, compliance with Florida Statutes for purchases, consultant selection, design and construction standards, permitting, insurance, and indemnification. The Recipient (Sumter County) will perform CEI services using its own forces. The agreement also specifies audit requirements and restrictions on vendors. [McNeill Drive Phase 5] The Sumter County Board of County Commissioners is accepting ownership and maintenance of McNeill Drive Phase 5, initiating a one-year warranty period. This project was previously approved on September 2, 2023, with a notice to proceed issued thereafter. The project is certified complete, with all inspections and repairs finalized. As-built drawings will be submitted prior to the warranty expiration. Reimbursement for project invoices will commence five years from receipt. [Sections 12 and 13, Township 20 South, Range 23 East, Sumter County, Florida; case JOB S01122.09960] This document details legal descriptions for land parcels within Sumter County, Florida, specifically within Sections 12 and 13 of Township 20 South, Range 23 East. It outlines boundaries and dimensions for right-of-way transfers related to McNeill Drive, Phase 5. The total area described is 8.62 acres. The document includes extensive survey data with bearings, distances, radii, and central angles, but does not state the applicant, case number, decision, or specific project type beyond right-of-way transfer. The Sumter County Board of County Commissioners is considering revising the Planner Job Description. The proposed change is to remove the requirement for a Certified Floodplain Manager certification, making it a preferred qualification. This aligns with the primary focus of floodplain activities on a dedicated Floodplain Manager and is a requirement for promotion to Assistant Planning Manager. The meeting date was May 12, 2026. [case 5307 Transit Grant Application] The Sumter County Board of County Commissioners is approving resolutions to delegate authority for the 5307 Transit Grant Application with the Federal Transit Administration (FTA). Sumter County Transit (SCT) is applying for this grant as part of the Lady Lake/The Villages Urbanized Area (UZA) following the 2020 Census. The grant will help defer operating expenses for Sumter County. The county administrator is authorized to execute and file the application. The meeting date was May 12, 2026. [11728 CR 207W, Oxford, FL 34484; case 2012-60020574] Sumter County Housing Services requested the execution of a Satisfaction of Mortgage for the State Housing Initiatives Partnership (SHIP) Program. The mortgage, originally for $9,750.30, was executed by Doug and Heather Stacey for repairs to their home at 11728 CR 207W, Oxford, FL 34484. The final payment was received on May 4, 2026, and the mortgage is now paid in full. Staff recommended approval.
- Board:
- Board of County Commissioners Regular Meeting
- Date:
- 2026-05-12
- Type:
- Packet
- Decision:
- Staff Recommends Approval for the ordinance creating the Tourist Development Council and levying a Tourist Development Tax.
- Address:
- 7375 Powell Road, Wildwood, FL 34785 (County Administrator's Office); 5497 Marsh Bend Trail, Grand Canyon Room, The Villages, FL 32163 (Meeting Location)
- Applicant:
- Sumter County Board of County Commissioners
May 4, 2026 Planning and Zoning Special Master Meeting Agenda
This document is an agenda for the Sumter County Planning and Zoning Special Master meeting on May 4, 2026. It lists two items for consideration: Minutes for Approval and two cases, LU26-000010 Holcomb and ZON26-000010 Holcomb. The agenda details the documents associated with each case, including staff reports, applications, and proof of publication. The meeting is scheduled for 5:00 PM at The Villages Sumter County Service Center, 7375 Powell Road, Wildwood, FL 34785, Room 102. The document also includes information on reasonable accommodation requests and contact information for the County Administrator's Office.
- Board:
- Planning and Zoning Special Master (PZSM)
- Date:
- 2026-05-04
- Type:
- Agenda
- Address:
- 7375 Powell Road, Wildwood, FL 34785, Room 102
- Applicant:
- Holcomb
May 4, 2026 Planning and Zoning Special Master Meeting Agenda packet 2026-05-04
The Sumter County Planning and Zoning Special Master meeting on May 4, 2026, included the approval of a Small Scale Comprehensive Plan Amendment and Rezoning Application for Mary Holcomb. The request was for a future land use change from Agriculture to Rural Residential and a zoning change from General Agriculture (A10C) / Rural Residential (RR5C) to Rural Residential Minimum One Acre (RR1C) for a 20.07-acre parcel. The Planning Division Staff recommended approval, finding the application in compliance with the Land Development Code and Comprehensive Plan. The Board of County Commissioners adopted Ordinance 2026- on May 26, 2026, approving the rezoning. The document also details other agenda items including minutes approval and other applications that were continued or had conditions of revocation. Public comment was received regarding the STU25-000067 Gulfstream Towers application, with a resident questioning the tower's location and the applicant requesting a continuance. Public comment was also received for the Medical Hardship Temporary Use Permit (STU25-000042 Vetto), with the applicant requesting an extension for the RV use to cease, which was granted with a modified condition.
- Board:
- Planning and Zoning Special Master (PZSM)
- Date:
- 2026-05-04
- Type:
- Packet
- Decision:
- Approved
- Address:
- 6075 C 575, Bushnell, FL 33513
- Applicant:
- Mary Holcomb
Special Master Code Enforcement Hearing April 30, 2026
This document is an agenda for a Special Master Code Enforcement Hearing for Sumter County, Florida, held on April 30, 2026. It details various code enforcement cases, including pre-hearing compliance, post-hearing affidavits, and code enforcement hearings for animal services, Coleman, Webster, County, and specific violations like nuisances, inoperable items, trash, debris, and unsafe structures. Many cases are listed as 'Compliant' with specific dates, while others are recommended for non-compliance with fines and staff costs. Specific cases include: 1. Donna Nevers at 25 Canal Way, Lake Panasoffkee, FL 33538, for FBC Section 105 Permits, status compliant 4/15/2026. 2. Tran Thi Van at 2805 CR 423, Lake Panasoffkee, FL 33538, for 2009 I.P.M.C. 304.7 Roofs & Drainage and Nuisances – Trash & Debris, status compliant 4/15/2026. 3. William K & Kimberley Marshall at 43 CR 489B, Lake Panasoffkee, FL 33538, for FBC Section 105 Permits, status compliant 4/10/2026. 4. Jermaine L & Bridgette J Canty at 324 N Market Blvd, Webster, FL 33597, for 2009 I.P.M.C. 302.8 Motor and 2009 I.P.M.C. 304.6 Exterior, status compliant 4/10/2026. 5. Vester Ray Taylor Sr. & Carol L Taylor at 9440 CR 735, Webster, FL 33597, for Sanitation and Nuisances – Trash & Debris and Nuisances – Inoperable, status compliant 4/17/2026. 6. Billy Joe Lawson, Jr & Lisa Douglas at 7686 CR 663, Bushnell, FL 33513, for SC-1051 FBC Section 105 Permits and 2009 I.P.M.C. 303.2 Enclosures, status compliant 4/17/2026. 7. Rodolfo G Estrada at 6957 CR 665 Bushnell, FL 33513, for Nuisances - Inoperable, status compliant 4/17/2026. 8. Billy W. & Mary J. Talley at 1171 W Parkhill Ave, Bushnell, FL 33513, for Nuisances Inoperable, status compliant 4/28/2026. 9. B W & Mary Talley at Vacant, W. Parkhill Ave, Bushnell, FL 33513, for Nuisances – Trash & Debris and Nuisances – Grass, status compliant 4/28/2026. 10. Adelbert Crosby at 8434 CR 109, Lady Lake, FL 32159, for Sanitation and Nuisances – Trash & Debris and Nuisances – Inoperable, status compliant 4/28/2026. 11. Hope Demons at 9173 CR 205A, Wildwood, FL 34785, for Nuisances – Trash &, status compliant 4/28/2026. 12. R & R Cattle Ranch, LLC at 419 N Market Blvd, Webster, FL 33597, for SC-1051 FBC Section 105 Permits, status compliant 4/29/2026. 13. Brenton W White Sr. & Angela M White at 7250 CR 663 Bushnell, FL 33513, for SC-1051 FBC Section 105 Permits, status compliant 4/29/2026. 14. Rose L Fletcher at 148 CR 532W, Bushnell, FL 33513, for 2009 I.P.M.C. 301.3 Vacant Structures & Land, 2009 I.P.M.C. 304.1.1 Unsafe Conditions, Nuisances – Trash & Debris, Nuisances – Grass. Property sold on 1/28/2026, case closed, new case opened under new owner(s) Case #26-005526 - Joel Perea. 15. Quality 1 Service, LLC at 5562 S US 301, Bushnell, FL 33513, for Nuisances – Inoperables, fines not paid, case sent for lien on 3/27/2026. 16. Belinda McMaster & Timothy John Spillane at Vacant CR 622B, Bushnell, FL 33513, for Nuisances – Trash & Debris and RV as Temporary Dwelling, fines not paid, violation 6-104.(2) out of compliance, violation Sec. 13-534 in compliance, case sent for lien on 3/27/2026. 17. Lafreda A. Gavin & Vivian Gavin at 725 NW 7th St, Webster, FL 33597, for 2009 I.P.M.C. 304.1.1 Unsafe and 2009 I.P.M.C. 304.13 Window, Skylight, and Door Frames, status compliant and fees paid. 18. Larry J Lewis at 1612 CR 434B. Lake Panasoffkee, FL 33538, for Sec 4-10 Dogs & Cats Running at Large and Sec. 4-7 Public Nuisance Animals, status compliant and fees paid. 19. Loren Wells at 2034 CR 439A, Lake Panasoffkee, FL 33538, for FBC Section 105 Permits and 2009 I.P.M.C. 604.3 Electrical Hazards, status compliant and fees paid. 20. Kenneth Dayton Mitchell Jr at 4695 CR 692, webster, FL 33597, for Nuisances – Trash &, Nuisances, Nuisances – Grass, status compliant and fees paid. 21. Randy Lee Fowler at 7656 CR 109G, Lady Lake, FL 32159, for Sec. 4-10 Dogs & Cats Running at Large, status compliant and fees paid. 22. Isaias-Valdez & Olivia Medrano at 609 W. Noble Ave, Bushnell, FL 33513. 23. Warllysson Rose Santana & Diana Ortiz at 1522 Rieves Dr, The Villages, FL 34762, for Sec. 4-10 Dogs and Cats Running at Large and Sec. 4-7. Public Nuisance Animals, recommended for non-compliance, pay staff costs of $187.72, $100 fine for first offense and $5.00 training for a total of $292.72 to be paid within 30 days. 24. Darlene Lee Zelent at 7783 CR 109E, Lady Lake, FL 32159, for Sec. 4-10 - Dogs and Cats Running at Large, recommended for non-compliance, pay staff costs of $187.72, $100 fine for first offense and $5.00 training for a total of $292.72 to be paid within 30 days. 25. Pauline Moore at 2507 Orange Ave, Coleman, FL 33521, for Sec. 13-531 Care Giver Residence, recommendation to grant continuation to May 28, 2026 hearing. 26. Quentin T Mobley at 370 NW 8th Ave, Webster, FL 33597, for WB-304.7 2009 I.P.M.C. 304.7 Roofs and drainage, recommended for non-compliance, pay staff costs by compliance date and $50 per day fine for every day past compliance date. 27. Rowshan Jilani & Islam Mohammed (H/W) at 1943 C-478A, WEBSTER, FL 33597, for 2009 I.P.M.C. 108.1.1 Unsafe Structures and 2009 I.P.M.C. 301.3 Vacant Structures and Land, recommended for non-compliance, pay staff costs by compliance date and $25 per day fine for every day past compliance date. 28. Oakland Hills 300, LLC at Sunshine 10, 13940 US 441, LADY LAKE, FL 32159, for Sec. 13-563. Internet Cafes, recommended to cease operation immediately and pay staff costs, assess $100 daily fine for each day business continues to operate. 29. Country Crossings Villages, LLC at Player's Palace, LLC dba Player's Palace, 13737 US 441, LADY LAKE, FL 32159, for Sec. 13-563. Internet Cafes, recommended to cease operation immediately and pay staff costs, assess $100 daily fine for each day business continues to operate. 30. Oakland Hills Center, LLC at Senior Social Center, 13940 US 441, LADY LAKE, FL 32159, for Sec. 13-563. Internet Cafes, recommended to cease operation immediately and pay staff costs, assess $100 daily fine for each day business continues to operate. 31. Derek J & Kelsey B Baker at 5587 SE 56th Ln, Center Hill, FL 33514, for Sec. 13-417. Land Uses, recommended for non-compliance, pay staff costs by compliance date and $25 per day fine for every day past compliance date. 32. Tracey L. Rose & Leathers S. Phillips at 2817 CR 423, Lake Panasoffkee, FL 33538, for 2009 I.P.M.C. 301.3 Vacant Structures and land, Sanitation Req-Care of Premises, Nuisances – Trash & Debris, Nuisances – Grass, Accumulation of Rubbish, Disposal of Rubbish, Disposal of Garbage, recommended for non-compliance, pay staff costs by compliance date and $25 per day fine for every day past compliance date. 33. Ashley Cowart at 355 N US 301, Sumterville, FL 33585, for Sec. 13-417. Land Uses and Nuisances - Inoperables, recommended for non-compliance, pay staff costs by compliance date and $25 per day fine for every day past compliance date. 34. Fidel Granados & Anita Andrews at 12405 SW 42nd Way, Webster, FL 33597, for Sec. 13-534. RV as temporary dwelling, recommended for non-compliance, pay staff costs by compliance date and $25 per day fine for every day past compliance date. 35. Alma Grisel Munoz at 1183 CR 482C 1, Lake Panasoffkee, FL 33538, for SC-1051 FBC Section 105 Permits [A] 105.1 Required, recommended for non-compliance, pay staff costs by compliance date and $25 per day fine for every day past compliance date. 36. Lazaro Heriberto F Perez & Haidara Rodriguez at 6093 SW 100th Ave, Bushnell, FL 33513, for Sec. 13-534. RV as temporary dwelling and FBC Section 105 Permits [A] 105.1 Required, recommended for non-compliance, pay staff costs by compliance date and $25 per day fine for every day past compliance date. 37. Cecil Creech & Cynthia Lynn Davis, H/W at 2141 CR 429 Lake Panasoffkee, FL 33538, for Sanitation, Accumulation of Rubbish, Disposal of Rubbish, Nuisances - Trash & Debris, recommended for non-compliance, pay staff costs by compliance date and $50 per day fine for every day past compliance date.
- Board:
- Code Enforcement Hearings - Special Master Hearings
- Date:
- 2026-04-30
- Type:
- Agenda
- Decision:
- Multiple decisions listed, including 'Compliant' with specific dates, 'Closed', 'Sent for lien', 'Recommended for non-compliance', 'Cease operation', and 'Grant request for continuation'.
- Address:
- Multiple addresses listed throughout the document for various code enforcement cases.
- Applicant:
- Multiple applicants/owners listed throughout the document for various code enforcement cases.
Special Master Code Enforcement Hearing April 30, 2026 packet 2026-04-30
[215 E. McCollum Ave., Bushnell, FL 33513] This document details a Special Master Code Enforcement Hearing held on April 30, 2026. It lists numerous cases categorized under Pre-Hearing Compliance, Post-Hearing Affidavit of Non-Compliance, and Code Enforcement Hearings for Animal Services, Coleman, Webster, and County matters. Most cases involve violations such as lack of permits, nuisances (trash, debris, inoperable items, overgrown grass), unsafe structures, and improper use of RVs as dwellings. Many cases are marked as 'Compliant' or 'Complaint' with specific compliance dates, indicating resolution or ongoing issues. A few cases are proceeding to lien filing due to unpaid fines. One case involves an internet cafe operating without a permit, with a recommendation to cease operations immediately and pay daily fines. Another case is a continuation request. The Animal Services section includes recommendations for fines and staff costs for violations related to dogs and cats running at large and public nuisance animals. [Vacant NE 107th Blvd, Lady Lake, FL 32162; case 26-000219 (SCPD)] Case 26-000219 (SCPD) involved an unpermitted block party on a vacant lot at NE 107th Blvd, Lady Lake, FL 32162. Approximately 500-600 people attended, with a DJ and event lighting, promoted on Facebook. Gunshots were fired, and a vehicle with bullet holes was found. The Special Master found the respondents, Alverlinda Walker and Jasper Shalonte, in non-compliance, ordering them to pay staff costs of $126.58 and a $500 fine for the first offense, totaling $626.58 within 30 days. [Vacant NE 106th LN, Lady Lake, FL 32159; case 26-000228 (SCPD)] Case 26-000228 (SCPD) involved an unpermitted block party on a vacant lot at NE 106th LN, Lady Lake, FL 32159. Approximately 1500 people attended, with a DJ and food vendors, advertised on Facebook, and hosts charged $20 per person. Gunshots were fired, and one victim was found. The Special Master found the respondents, Georgia and Todrick Rambo, in non-compliance, ordering them to pay staff costs of $126.58 and a $500 fine for the first offense, totaling $626.58 within 30 days. [8828 NE 107 BLVD, Lady Lake, FL 32162; case 26-000228 (SCPD)] Case 26-000228 (SCPD) involved an unpermitted block party at 8828 NE 107 BLVD, Lady Lake, FL 32162. The incident occurred on December 27, 2025. Sgt. Larry Thompson testified about the large number of attendees, DJ, event lighting, and promoted event on Facebook. Extra deputies were called in, and a vehicle with bullet holes was found. Eva Brooks stated she slept through the event and her daughter Kanisha stated they did not allow overflow cars to park on their property and spent the evening chasing people off their property. The Special Master found the property not in violation and assigned no fees or fines. [1612 CR 434B, Lake Panasoffkee, FL 33538; case 25-023643 (SCAS)] Case 25-023643 (SCAS) involved violations of Sec. 4-10 (Dogs and Cats Running at Large) and Sec. 4-7 (Public Nuisance Animals) at 1612 CR 434B, Lake Panasoffkee, FL 33538. The case began on November 27, 2025. The Special Master ordered the respondent, Larry J Lewis, to pay staff costs of $118.46, a $100 fine for the first offense, and a $5 training fee, totaling $223.46 within 30 days. [2547 CR 722, Webster, FL 33597; case 25-021602 (SCAS)] Case 25-021602 (SCAS) involved violations of Sec. 4-6 (Licensure and Rabies Vaccination of Dogs, Cats) at 2547 CR 722, Webster, FL 33597. The case began on October 17, 2025. Officer McDaniel testified that 38 cats were not up to date on rabies vaccinations and one had an apparent eye infection. Ms. Bemus-Mikolajek testified she no longer had any of the cats except her own four. The Special Master found the property not in violation and assigned no fees or fines. [3357 W C-476, Bushnell, FL 33513; case 25-021276 (SCAS)] Case 25-021276 (SCAS) involved violations of Sec. 4-7 (Public Nuisance Animals) at 3357 W C-476, Bushnell, FL 33513. The case began on August 22, 2025. Officer McDaniel stated there was a previous case regarding the neighbor's peacocks on the complainant's property. The Special Master ordered the respondent, Bruce C Jordan, to pay staff costs of $109.60, a $100 fine for the first offense, a $175 fine for the second offense, and a $5 training fee, totaling $389.60 within 30 days. [260 NE 3rd St, Webster, FL 33597; case 25-021352 (WEBSTER)] Case 25-021352 (WEBSTER) involved violations of 2009 I.P.M.C. 302.4 (Weeds), 304.4 (Structural members), and 304.7 (Roofs and drainage) at 260 NE 3rd St, Webster, FL 33597. The case began on November 13, 2025. The Special Master found the property to be in violation and ordered the respondent, Maia-Goncalves Jose & Dasilva, to bring the property into compliance within 180 days, pay Staff Costs of $415.44, and a $25 per day fine for every day the property remains in violation after July 28, 2026. [483 NW 9th Ave, Webster, FL 33597; case 25-021370 (Webster)] Case 25-021370 (Webster) involved violations of 2009 I.P.M.C. 304.7 (Roofs and drainage) at 483 NW 9th Ave, Webster, FL 33597. The case began on November 14, 2025. The Special Master found the property to be in violation and ordered the respondent, Beulah Baptist Church, to bring the property into compliance within 30 days, pay Staff Costs of $415.44, and a $100 per day fine for every day the property remains in violation after February 28, 2026. [Vacant CR 513, Wildwood, FL 34785; case 25-016979] Case 25-016979 involved violations of Sec. 13-534 (RV as temporary dwelling) at Vacant CR 513, Wildwood, FL 34785. The case began on September 3, 2025. The Special Master found the property to be in violation and ordered the respondent, Smitherman, Louise & Richard E (TIC), to bring the property into compliance within 180 days, pay Staff Costs of $415.44, and a $25 per day fine for every day the property remains in violation after July 28, 2026. [148 CR 532, Bushnell, FL 33513; case 25-020065] Case 25-020065 involved violations of 2009 I.P.M.C. 301.3 (Vacant structures and land), SC-304.1.1-2009 I.P.M.C. 304.1.1 (Unsafe conditions), 6-104.(2) (Nuisances – Trash & Debris), and 6-104.(5) (Nuisances – Grass) at 148 CR 532, Bushnell, FL 33513. The case began on October 21, 2025. The Special Master found the property to be in violation and ordered the respondent, Rose Fletcher, to bring the property into compliance within 30 days, pay Staff Costs of $415.44, and a $25 per day fine for every day the property remains in violation after February 28, 2026. The property was sold on January 28, 2026. [5118 CR 167, Wildwood, FL 34785; case 25-020557] Case 25-020557 involved violations of FBC Section 105 Permits [A] 105.1 (Required) at 5118 CR 167, Wildwood, FL 34785. The case began on October 28, 2025. The Special Master found the property to be in violation and ordered the respondent, Messenger Dorothy (TTEE), to bring the property into compliance within 180 days, pay Staff Costs of $415.44, and a $25 per day fine for every day the property remains in violation after July 28, 2026. [2946 CR 238, Wildwood, FL 34785; case 25-021121] Case 25-021121 involved violations of 2009 I.P.M.C. 301.3 (Vacant structures and land) and SC-304.1.1-2009 I.P.M.C. 304.1.1 (Unsafe Conditions) at 2946 CR 238, Wildwood, FL 34785. The case began on November 7, 2025. The Special Master found the property to be in violation and ordered the respondents, Evans Marva & Samuel C (JT), to bring the property into compliance within 30 days, pay Staff Costs of $415.44, and a $25 per day fine for every day the property remains in violation after February 28, 2026. An extension was granted, making the new compliance date May 29, 2026. [5562 S US 301, Bushnell, FL 33513; case 25-021660] Case 25-021660 involved violations of 6-104.(4) (Nuisances – Inoperable) at 5562 S US 301, Bushnell, FL 33513. The case began on November 18, 2025. The Special Master found the property to be in violation and ordered the respondent, Quality 1 Service, LLC, to bring the property into compliance within 30 days, pay Staff Costs of $415.44, and a $100 per day fine for every day the property remains in violation after February 28, 2026. [Vacant CR 622, Bushnell, FL 33513; case 25-022270] Case 25-022270 involved violations of Sec. 13-517 (Storage buildings), 2009 I.P.M.C. 301.3 (Vacant structures and land), and 6-104.(2) (Nuisances – Trash & debris) at Vacant CR 622, Bushnell, FL 33513. The case began on December 3, 2025. The Special Master found the property to be in violation and ordered the respondents, Hatley Brenda K & Hatley David L (JT), to bring the property into compliance within 90 days, pay Staff Costs of $415.44, and a $10 per day fine for every day the property remains in violation after April 29, 2026. [30 CR 416 S, Lake Panasoffkee, FL 33538; case 25-022347] Case 25-022347 involved violations of Sec. 13 – 417 (Land uses) and Sec. 13 – 513 (Home-based business) at 30 CR 416 S, Lake Panasoffkee, FL 33538. The case began on November 25, 2025. Inspector Vann stated the respondent is renting space for RV & Boat storage and provided an advertisement for the business. The Special Master found the property to be in violation and ordered the respondents, McGonigle Craig & Goshow Craig & McGonigle Dee (TIC), to bring the property into compliance within 30 days, pay Staff Costs of $415.44, and a $25 per day fine for every day the property remains in violation after February 28, 2026. [Vacant CR 622B, Bushnell, FL 33513; case 25-022418] Case 25-022418 involved violations of Sec. 13-534 (RV as temporary dwelling), 2009 I.P.M.C. 301.3 (Vacant structures and land), and 6-104.(2) (Nuisances – Trash & debris) at Vacant CR 622B, Bushnell, FL 33513. The case began on November 26, 2025. The Special Master found the property to be in violation and ordered the respondents, McMaster Belinda & Spillane Timothy John (ETAL), to bring the property into compliance within 30 days, pay Staff Costs of $415.44, and a $25 per day fine for every day the property remains in violation after February 28, 2026. [791 NW 4th St, Webster, FL 33597; case 25-011703 (Webster)] Case 25-011703 (Webster) was an extension request for violations of 2009 I.P.M.C. 302.1 (Sanitation), 304.7 (Roofs and drainage), 308.1 (Accumulation of rubbish), 308.2 (Disposal of rubbish), and 308.2.1 (Rubbish storage facilities) at 791 NW 4th St, Webster, FL 33597. The ordered compliance date was February 24, 2026. Special Master Hawkins granted an additional 90-day extension, making the new compliance date May 24, 2026. [9105 CR 647C, Bushnell, FL 33513; case 25-016877] Case 25-016877 was an extension request for violations of 2009 I.P.M.C. 301.3 (Vacant Structures and Land) and 304.1.1 (Unsafe Conditions) at 9105 CR 647C, Bushnell, FL 33513. The ordered compliance date was January 19, 2026. Special Master Hawkins granted an additional 180-day extension, making the new compliance date July 19, 2026. [case 25-013333] Case 25-013333, with a compliance date of May 16, 2026, was approved as an Affidavit of Partial-Compliance, with outstanding costs in the amount of $414.74. [7656 CR 109G, Lady Lake, FL 32159; case 25-021612 (SCAS)] Case 25-021612 (SCAS) involved violations of Sec. 4-10 (Dogs & Cats Running at Large) at 7656 CR 109G, Lady Lake, FL 32159. The case began on August 20, 2025. ACO Liam Stratton testified about a nuisance dog complaint and photos of the dog wandering. ACO Philip Pace testified about a dog running at large complaint. Ms. Bowman stated she was moving and the dog would no longer be wandering. Special Master Hawkins ordered staff costs of $176.36, a $100 fee for the first offense, and a $5 training fee, totaling $277.36 to be paid within 30 days. [4060 NE 42nd Loop, Wildwood, FL 34785; case 25-021679 (SCAS)] Case 25-021679 (SCAS) involved violations of Sec. 4-10 (Dogs and Cats Running at Large) at 4060 NE 42nd Loop, Wildwood, FL 34785. The case began on October 11, 2025. Ms. Tonn stated her estranged husband let the dogs out. Special Master Hawkins ordered staff costs of $180.48, a $200 fee for a repeat offense, and a $5 training fee, totaling $385.48 to be paid within 30 days. [5924 SW 42nd St, Bushnell, FL 33513; case 25-023663] Case 25-023663 involved violations of Sec. 4-10 (Dogs & Cats Running at Large) and Sec. 4-7 (Public Nuisance Animals) at 5924 SW 42nd St, Bushnell, FL 33513. The case began on November 11, 2025. Mr. Short stated he was caring for a friend's dog, which got out and attacked a neighbor's cat. The dog is no longer in his care. Special Master Hawkins found no violation and no further action to be taken. [3768 CR 513, Wildwood, FL 34785; case 26-000387 (SCAS)] Case 26-000387 (SCAS) involved violations of Sec. 4-10 (Dogs & Cats Running at Large) at 3768 CR 513, Wildwood, FL 34785. The case began on July 18, 2025. Mr. De La Cruz stated he is looking for a new home for the animal. Special Master ordered staff costs of $228.06, a $600 fine for three repeat offenses, and a $5 training fee, totaling $833.06 to be paid within 30 days. [841 NW 7th St., Webster, FL 33514; case 26-000187 (Webster)] Case 26-000187 (Webster) involved violations of 2009 I.P.M.C. 304.15 (Doors), 304.6 (Exterior Walls), 304.7 (Roofs and Drainage), 504.1 (General), and 604.3 (Electrical System Hazards) at 841 NW 7th St., Webster, FL 33514. The case began on January 8, 2026. Special Master Hawkins ordered 30 days to be in compliance and pay staff costs of $415.44. There will be a $25 per day fine and any additional staff costs for every day the property remains out of compliance past March 28, 2026. An extension was granted, making the new compliance date September 28, 2026. [6804 CR 213, Wildwood, FL 34785; case 26-000329] Case 26-000329 involved violations of 2009 I.P.M.C. 304.7 (Roofs and Drainage), 305.4 (Stairs and Walking Surfaces), and FBC Section 105 Permits [A] 105.1 (Required) at 6804 CR 213, Wildwood, FL 34785. The case began on January 8, 2026. Mr. Weaver stated permits for the roof and windows have been issued and requested three weeks to complete the project. Special Master Hawkins ordered 30 days to be in compliance and pay staff costs of $415.44. There will be a $25.00 per day fine and any additional staff costs for every day the property remains out of compliance past April 25, 2026. [2932 CR 238, Wildwood, FL 34785; case 26-001252] Case 26-001252 involved violations of 2009 I.P.M.C. 304.7 (Roofs and Drainage), 305.4 (Stairs and Walking Surfaces), and FBC Section 105 Permits [A] 105.1 (Required) at 2932 CR 238, Wildwood, FL 34785. The case began on January 22, 2026. Special Master ordered 30 days to be in compliance and pay staff costs of $415.44. There will be a $25.00 per day fine and any additional staff costs for every day the property remains out of compliance past April 25, 2026. [11441 CR 678, Webster, FL 33597; case 26-001268] Case 26-001268 involved violations of 2009 I.P.M.C. 301.3 (Vacant structures and Land), 304.13 (Window, Skylight, and Door Frames), and 6-104.(5) (Nuisances – Grass) at 11441 CR 678, Webster, FL 33597. The case began on January 23, 2026. Special Master ordered 30 days to be in compliance and pay staff costs of $415.44. There will be a $25 per day fine and any additional staff costs for every day the property remains out of compliance past April 25, 2026. [case 25-015636] Case 25-015636 was approved as an Affidavit of Compliance, with no outstanding costs. The compliance date was January 28, 2026. [case 25-019099] Case 25-019099 was approved as an Affidavit of Compliance, with no outstanding costs. The compliance date was February 10, 2026. [case 25-013771] Case 25-013771 was approved as an Affidavit of Compliance, with no outstanding costs. The compliance date was January 20, 2026. [case 25-021370] Case 25-021370 (Beulah Baptist Church) was approved as an Affidavit of Compliance, with no outstanding costs. The compliance date was March 16, 2026. [2825 Perkins Ave, Coleman, FL 33521; case 26-000298 (Coleman)] Case 26-000298 (Coleman) involved violations of 2000-5, Secs 1, 2, & 3 at 2825 Perkins Ave, Coleman, FL 33521. The case began on January 8, 2026. Special Master Hawkins ordered 30 days to be in compliance and pay staff costs of $415.44. There will be a $25.00 per day fine and any additional staff costs for every day the property remains out of compliance past April 25, 2026. [5573 Williamsburg Ln, Wildwood, FL 34785; case 26-003511 (SCAS)] Case 26-0003511 (SCAS) involved violations of Sec. 4-10 (Dogs and Cats Running at Large) and Sec. 4-7.0 (Public Nuisance Animals) at 5573 Williamsburg Ln, Wildwood, FL 34785. The case began on October 11, 2025. ACO Sierra Hollinger testified that the respondents' dog, Princess, bit Deputy Ellis. The respondents testified they were working on training the dog and there have been no problems since. Special Master Hawkins ordered the respondents to pay staff costs of $122.72 and a $100 fine for the first offense, for a total of $222.72 within 30 days. [130 CR 534, Bushnell, FL 33513-3452; case 26-003438 (SCAS)] Case 26-003438 (SCAS) involved violations of Sec. 4-10 (Dogs and Cats Running at Large) and Sec. 4-7.0 (Public Nuisance Animals) at 130 CR 534, Bushnell, FL 33513-3452. The case began on December 1, 2025. ACO Sierra Hollinger responded to a complaint about nuisance cats. Ms. Gilmer testified her cats are not loose and the cat in the pictures is not hers. Special Master Hawkins found there to be no violation at this time and assigned no fees or fines to the Respondent. [2327 CR 436A, Lake Panasoffkee, FL 33538; case 26-003318 (SCAS)] Case 26-003318 (SCAS) involved violations of Sec. 4-10 (Dogs and Cats Running at Large) and Sec. 4-7.0 (Public Nuisance Animals) at 2327 CR 436A, Lake Panasoffkee, FL 33538. This is a repeat case with previous SCAS case numbers #3885 and #3667. Officer Christopher McDaniel testified. Special Master Hawkins ordered the respondents to pay staff costs of $205.44 and a $250 fine for the third offense, plus a $5 training fee, for a total of $460.44. [1522 RIEVES DR, THE VILLAGES, FL 34762; case 26-004049] Case 26-004049 involves violations of Sec. 4-10 (Dogs and Cats Running at Large) and Sec. 4-7 (Public Nuisance Animals) at 1522 RIEVES DR, THE VILLAGES, FL 34762. The violation was first observed on February 5, 2026. The Special Master ordered the respondents, Santana Warllysson Rosa & Diana Ortiz, to pay staff costs of $292.72, including a $100 first offense fine and a $5 training surcharge. A hearing is scheduled for 04/30/2026. [7783 CR 109E, COLEMAN, FL 33521; case 26-005879] Code enforcement case regarding an unsafe and vacant structure at 7783 CR 109E, Coleman, FL. The property has overgrown vegetation and vines on the structure. The case was initiated on 2/16/26 and a hearing is scheduled for May 28, 2026. Staff recommends granting a continuation. The property has a history of probate issues and an adverse possession claim. [2507 ORANGE AVE, COLEMAN, FL 33521; case 26-002962] Code enforcement case for an illegal residence (mobile home) at 2507 Orange Ave, Coleman, FL. The property owner is deceased. The case was initiated on 2/16/26. Staff recommends granting a continuation to the May 28, 2026 hearing. The property has an adverse possession claim on file. [370 NW 8TH AVE, WEBSTER, FL 33597; case 26-004240] Code enforcement case for repeat violations including inoperable vehicles and possible roof issues at 370 NW 8th Ave, Webster, FL. The case was initiated on 3/2/26. Staff recommends the property owner cease operation immediately and pay staff costs and a daily fine. [1943 C -478A, WEBSTER, FL 33597; case 26-003539] Code enforcement case for an unsafe structure and overgrown property at 1943 C -478A, Webster, FL. The structure is vacant and damaged by fire, with a collapsed roof and overgrown vegetation. The case was initiated on 2/21/26. A hearing was scheduled for 04/30/2026. The property owner requested more time to obtain demolition permits. Staff recommends the property owner pay costs and a daily fine if compliance is not met. [13940 US 441, LADY LAKE, FL 32159; case 24-006397] Code enforcement case for operating an internet cafe (Sunshine 10) without a permit at 13940 US 441, Lady Lake, FL. The business was operating after its permit was revoked. The case was initiated on 12/30/24. A hearing was scheduled for 04/30/2026. Staff recommends ceasing operations immediately and paying staff costs and a daily fine. [13940 US 441, LADY LAKE, FL 32159; case 24-006397] OAKLAND HILLS 300 LLC is involved in a code violation case for operating an internet cafe without a permit at 13940 US 441, Lady Lake, FL. The violation was first observed on 9/12/2025 and a hearing is scheduled for 04/30/2026. The property owner is OAKLAND HILLS 300 LLC. [13737 US 441, LADY LAKE, FL 32159; case 24-006398] COUNTY CROSSINGS VILLAGES, LLC is involved in a code violation case for operating an internet cafe without a permit at 13737 US 441, Lady Lake, FL. The violation was first observed on 03/17/2026 and a hearing is scheduled for 04/30/2026. The property owner is COUNTY CROSSINGS VILLAGES, LLC. [13741 N. US HWY 441, LADY LAKE, FL 32159; case 24-006398] PLAYER'S PALACE, LLC dba PLAYER'S PALACE is involved in a code violation case for operating an internet cafe without a permit at 13737 US 441, Lady Lake, FL. The violation was first observed on 03/17/2026 and a hearing is scheduled for 04/30/2026. The property owner is COUNTY CROSSINGS VILLAGES, LLC. [13737 US 441, LADY LAKE, FL 32159; case 24-006398] Code violation case against COUNTY CROSSINGS VILLAGES, LLC for operating an internet cafe without a permit at 13737 US 441, Lady Lake, FL. The violation was first observed on 03/17/2026 and referred to the Code Special Master on 03/31/2026. A hearing notice was posted on 04/20/2026. [13940 US 441, LADY LAKE, FL 32159; case 24-006399] Code violation case against OAKLAND HILLS CENTER LLC for operating an internet cafe without a permit at 13940 US 441, Lady Lake, FL. The violation was first observed on 02/04/2026 and referred to the Code Special Master on 03/31/2026. A hearing was scheduled for 04/30/2026. The case involves staff costs of $474.48 and a potential $100 daily fine. [5587 SE 56TH LN, CENTER HILL, FL 33514; case 26-002533] Code violation case against DEREK J & KELSEY B BAKER for unauthorized grading and damage to a private easement road by commercial activity at 5587 SE 56TH LN, Center Hill, FL. The violation was first observed on 02/10/2026. A hearing was scheduled for 04/16/2026. The case involves staff costs of $415.44 and a potential $25.00 daily fine. [2817 CR 423, LAKE PANASOFFKEE, FL 33538; case 26-002542] Code violation case against TRACEY L ROSE & LEATHERS PHILLIPS for violations including improper garbage disposal and vacant land maintenance at 2817 CR 423, Lake Panasoffkee, FL. The violation was first observed on 02/10/2026. The case involves potential fines and costs. [2817 CR 423; case 26-002542] Code enforcement case regarding tall grass/weeds, trash, and debris at 2817 CR 423. The property is a vacant residence. Violations include overgrowth of vegetation exceeding 24 inches, accumulation of trash and debris, and garbage in the driveway. A hearing was scheduled for April 30, 2026, with costs of $415.44 due by April 15, 2026, and a daily fine of $25.00 for non-compliance. [355 N US 301; case 26-003199] Code enforcement case regarding trash, debris, and tractor-trailer containers on site at 355 N US 301. The property is zoned AG/IMP w/out HX and is 26.71 acres. Violations include accumulation of trash and debris, and the presence of inoperable vehicles. A hearing was scheduled for April 16, 2026, with costs of $415.44 due by the compliance date and a daily fine of $25.00 for non-compliance. [12405 SW 42ND WAY; case 26-003284] Code enforcement case regarding RVs being lived in and a shed being lived in at 12405 SW 42ND WAY. The property is 0.835 acres and is zoned for mobile homes. Violations relate to the use of RVs as temporary dwellings exceeding the allowed five-day period and potentially living in a shed. A hearing was scheduled for April 16, 2026, with costs of $415.44 due by the compliance date and a daily fine of $25.00 for non-compliance. [1183 CR 482C 1; case 26-004143] Code enforcement case regarding the construction of a new home without a permit at 1183 CR 482C 1. The property is 0.168 acres and is zoned for mobile homes. The violation is related to FBC Section 105.1, requiring a permit for construction. A hearing was scheduled for April 16, 2026, with costs of $415.44 due by April 14, 2026, and a daily fine of $25.00 for non-compliance. [2141 CR 429; case 26-004761] Code enforcement case regarding sanitation, trash, debris, and inoperable vehicles at 2141 CR 429. This is a repeat offender case. Violations include accumulation of rubbish, trash, garbage, and inoperable vehicles. A hearing was scheduled for April 30, 2026, with costs of $336.58 due by April 15, 2026, and a daily fine of $50.00 for non-compliance. [2141 CR 429, LAKE PANASOFFKEE, FL 33538; case 26-004761] This record details a Code Compliance Hearing for a property located at 2141 CR 429, Lake Panasoffkee, FL 33538. The violation involves the open storage of old tires, appliances, and other scrap, along with three inoperable vehicles (a black SUV, an older model Ford pickup, and a motor home) on the property. Additionally, vehicles and trailers loaded with tires are stored on the right-of-way on CR 429 and CR 429B. The property owners are Creech Cecil and Davis Cynthia Lynn H/W. The case number is 26-004761. The violation was first observed on March 10, 2026, and a notice of violation was issued on March 11, 2026. The document outlines the procedures for code compliance hearings, including the presentation of cases, witness testimony, and the potential for orders to comply or further proceedings. Public comment or stakeholder sentiment is not stated in this portion of the document.
- Board:
- Code Enforcement Hearings - Special Master Hearings
- Date:
- 2026-04-30
- Type:
- Packet
- Decision:
- Find in Non-Compliance, pay staff costs and fine
- Address:
- 215 E. McCollum Ave., Bushnell, FL 33513
- Applicant:
- Alverlinda Walker and Jasper Shalonte
April 28, 2026 Regular Meeting Agenda
[5497 Marsh Bend Trail, Grand Canyon Room, The Villages, FL 32163; case ZON26-000007] Rezoning of 7.5 Acres MOL from Rural Residential Minimum Five (5) Acres with Conventional Housing (RR5C) to Rural Residential Minimum Five (5) Acres with Optional Housing (RR5) to permit the placement of one (1) Class B Mobile Home. Staff recommends approval. The meeting is scheduled for April 28, 2026, at 6:00 PM at the Everglades Regional Recreation Center, 5497 Marsh Bend Trail, Grand Canyon Room, The Villages, FL 32163. [C17-014; case S2021-0007] Sumter County intends to revoke a Special Use Permit that allows a Sixty (60) Seat Church on Parcel C17-014. Staff recommends revocation of the Special Use Permit. The meeting is scheduled for April 28, 2026, at 6:00 PM at the Everglades Regional Recreation Center, 5497 Marsh Bend Trail, Grand Canyon Room, The Villages, FL 32163. Proclamation recognizing the week of April 26 - May 2, 2026, as National Apprenticeship Appreciation Week in Sumter County. Proclamation recognizing May 4 - 8, 2026, as Economic Development Week in Sumter County. Proclamation recognizing May 8, 2026, as Child Care Provider Appreciation Day in Sumter County. [7854 SR 471 / N24-042] Discussion regarding 7854 SR 471 / N24-042 for direction. [Heart of Florida Landfill] Letter from District 52 State Representative regarding the Permitted Exploratory Deep Injection Well at the Heart of Florida Landfill. Final Integrated Water Quality Assessment for Florida and Landfills Article. City of Bushnell Response to WESH 2. RND Organics. FDEP Central District Quarterly Newsletter. ECFRPC Impact Reports and County Roll Up Reports. Letter of Designation for the Central Florida Crimeline, Inc. as a Recipient of The Crime Stoppers Trust Fund Funding. Woodland Crossings Community Development District Budget. Florida Small Business Development Center (SBDC) at University of Central Florida (UCF) - Sumter County Quarterly Performance Report. [N. Morse Boulevard] N. Morse Boulevard Multimodal Path Safety Recommendations to the AAC. [SR 44 from West of I-75 to East of CR 229] State Road (SR) 44 Resurfacing from West of I-75 to East of CR 229. [Heart of Florida Landfill] Letter to A.C.M.S., Inc. Regarding Heart of Florida Landfill. Florida PACE Funding Agency vs. Sumter County Tax Collector. FL RV Village Wildwood, LLC, et al. vs. Sumter County. Skytop Ranch LLC Bankruptcy Case Engagement Agreement for Legal Representation for Sumter County Regarding this Case. Emergency Motion Regarding Sunshine 10, LLC dba Sunshine Arcade vs. Sumter County BOCC. Emergency Motion Regarding Villages 2018, LLC dba Senior Social Center vs. Sumter County. Emergency Motion Regarding Player's Palace, LLC vs. Sumter County. March 2026 Check Register. Minutes from the January 13, 2026 Regular Meeting. Minutes from the February 17, 2026 Workshop Meeting. Minutes from the March 10, 2026 Regular Meeting. [5497 Marsh Bend Trail, The Villages, FL 34785] Set Public Hearing for May 12, 2026, at 6:00 PM at the Everglades Recreation Center, 5497 Marsh Bend Trail, The Villages, FL 34785, to Adopt an Ordinance Establishing the Tourist Development Council and Advertise for Applications. Affordable Housing Advisory Committee (AHAC) One (1) Vacancy. Construction Industry Licensing/Fire Code Board of Appeals Three (3) Vacancies. Industrial Development Authority One (1) Vacancy. Library Technology Advisory Board (LTAB), Two (2) Vacancies. Public Safety Coordinating Council Six (6) Vacancies. [case A-13] Budget Amendment A-13 for FY 2025/2026. Purchase Order Approval for FY 2025/2026. Inventory Transactions - Disposal, Surplus, and Transfer of Property. [948 CR 461, Lake Panasoffkee, FL 33538] Review Purchase Offers for Surplus Parcel J04E006 – 948 CR 461, Lake Panasoffkee, FL 33538. Acceptance of Florida Local Government Cybersecurity Grant Year 3. [between C 469 and Lake County Line] Agreements for Purchase of Wetland Mitigation Credits for C 48 Improvement Project between C 469 and Lake County Line. Amendment 1 of Agreement with Motorola Solutions, Inc for BRINC MSI Takeoff Program. Approval of Motion for Entry of Stipulated Final Judgment with AQ Old Mill, LLC. [case MOU No. 5] Memorandum of Understanding (MOU) #5 Between Sumter County Board of County Commissioners and the Professional Firefighters of Sumter County, International Association of Firefighters Local 5313, Rank and File Unit. [case MOU No. 6] Memorandum of Understanding (MOU) #6 Between Sumter County Board of County Commissioners and the Professional Firefighters of Sumter County, International Association of Firefighters Local 5313, Supervisory Unit. [County-Wide; case Task Order 11] Task Order 11 with DRMP and Sumter County Board of County Commissioners (BOCC) for Phase One of County-Wide Condition Assessment for Sign Panels, Supports, and Retroreflectivity. The School Safety Program FY 2026-2027 Agreement Between The Villages Charter School, Inc., The Board of County Commissioners of Sumter County, Florida, and the Sumter County Sheriff's Office. The School Safety Program FY 2026-2027 Agreement Between The School Board of Sumter County, Florida, The Board of County Commissioners of Sumter County, Florida, and the Sumter County Sheriff's Office. First Amendment to Settlement Agreement with Olympus Painting, Inc. Business Associate Agreement with Sumter County Sheriff for Drone Logistics System Integration with 911 Call-Taking Services. [case SS4A] Accept the Safe Streets and Roads for All (SS4A) Comprehensive Safety Action Plan (CSAP). Approval of Waiver of Fines and Release of Lien for Kenneth Mitchell, Jr. Correction Due to Clerk's Scriveners Error, the Recording Page Number of the Civil Restitution Lien was Listed Incorrectly on Satisfaction for Kevin Edwin Thompson. [The Bushnell Tax Collector Office; case Resolution 2026-] Resolution to Rename The Bushnell Tax Collector Office to the Tom Swain Tax Collector's Office.
- Board:
- Board of County Commissioners Regular Meeting
- Date:
- 2026-04-28
- Type:
- Agenda
- Decision:
- Staff Recommends Approval
- Address:
- 5497 Marsh Bend Trail, Grand Canyon Room, The Villages, FL 32163
- Applicant:
- Himes
April 28, 2026 Regular Meeting Agenda packet 2026-04-28
[601 C-478A; case ZON26-000007] The Sumter County Board of County Commissioners considered a rezoning request for 7.5 acres. The property, owned by Timothy and Vivian Himes, was rezoned from Rural Residential Minimum Five (5) Acres with Conventional Housing (RR5C) to Rural Residential Minimum Five (5) Acres with Optional Housing (RR5). This change permits the placement of one Class B mobile home. The Planning and Zoning Special Master recommended approval on April 6, 2026, and the Board of County Commissioners approved the request on April 28, 2026. The property is located in an unincorporated area north of C 478A and west of SR 50. The rezoning addresses a personal need for housing and is considered consistent with surrounding property uses and the Comprehensive Plan. No public opposition was noted; only positive written comments were received. [case ZON26-000007] Sumter County Planning and Zoning Special Master held a public hearing on April 6, 2026, to consider a rezoning application for 7.5 acres. The applicant, James Wade III, requested to rezone the property from Rural Residential Minimum Five Acres with Conventional Housing (RR5C) to Rural Residential Minimum Five Acres with Optional Housing (RR5) to allow for one Class B mobile home. The Special Master's recommendation will be presented to the Board of County Commissioners on April 28, 2026. The document also notes a separate action regarding the potential revocation of a Special Use Permit for Sts. Joachim and Anna Orthodox Church due to alleged violations. [1961 CR 246S, Oxford, FL 34484; case S2021-0007] Sumter County Board of County Commissioners considered the revocation of Special Use Permit S2021-0007 for Sts. Joachim and Anna Orthodox Church, located at 1961 CR 246S, Oxford, FL 34484, on parcel C17-014. The permit allowed a sixty (60) seat church. The county issued a Notice of Intent to Revoke on April 10, 2026, citing violations including an RV used as a residence, a semi-trailer not permitted, and accumulation of trash and debris, observed on February 17, 2026. The church requested a revocation hearing, stating they have addressed the violations. The Board of County Commissioners held a public hearing on April 28, 2026, to consider the revocation. The document also includes a resolution approving rezoning application ZON26-000007. [case Not applicable] The Board of County Commissioners of Sumter County, Florida, proclaimed the week of April 26 – May 2, 2026, as National Apprenticeship Appreciation Week. This proclamation recognizes the role of Registered Apprenticeships in developing a skilled workforce and supporting career pathways. It highlights Florida's ranking in talent attraction and the efforts of CareerSource Central Florida in supporting apprenticeship programs. [case Not applicable] The Board of County Commissioners of Sumter County, Florida, proclaimed the week of May 4th – May 8th, 2026, as Economic Development Week. This proclamation commends the Sumter County Economic Development team for their work in promoting economic well-being, supporting businesses, creating jobs, and facilitating county growth. [case Not applicable] The Board of County Commissioners of Sumter County, Florida, proclaimed May 8, 2026, as Child Care Provider Appreciation Day. This proclamation celebrates the contributions of early care and education providers in nurturing children, supporting families, and strengthening the local economy. It acknowledges the role of the Early Learning Coalition of the Nature Coast. [7854 SR 471; case N24-042] Bradley Arnold, County Administrator, informed Chris Thompson that the Board of County Commissioners would be approached on April 28, 2026, for direction regarding the potential acquisition of Thompson's property at 7854 SR 471 for integration with the fairgrounds. If the Board supports pursuing the property, an appraiser will be engaged to coordinate a site visit. [7854 SR 471, Bushnell, FL 33513; case N24-042] This document contains correspondence regarding the potential acquisition of property at 7854 SR 471, Bushnell, FL 33513, by Sumter County for fairgrounds expansion. Chris Thompson, the property owner, is open to offers and has 300 feet of road-front access. The County Administrator, Bradley Arnold, is seeking direction from the Board of County Commissioners (BOCC) to proceed with an appraisal and offer. The strategic plan for fairgrounds expansion is expected by the end of the month. The document also includes a letter from State Representative Samantha Scott to the Florida Department of Environmental Protection expressing concerns about an exploratory deep injection well at the Heart of Florida Landfill in Sumter County, citing potential risks to the Floridan Aquifer. Additionally, it contains the Florida Department of Environmental Protection's 2018 Integrated Water Quality Assessment report, detailing surface and groundwater quality, impaired waters, and water quality initiatives across Florida. This document is a report on Florida's water quality assessment, focusing on monitoring networks, chemical tracers, harmful algal blooms, and sediment quality. It details the methodology and results of statewide probabilistic and trend monitoring of rivers, streams, canals, and lakes from 2014-2016. The report identifies frequently detected pesticides and discusses their impact. It also outlines the state's approach to managing nutrient enrichment and harmful algal blooms, including the use of chemical tracers and the development of Numeric Nutrient Criteria (NNC). The document details the Triennial Review of Florida's Water Quality Standards, which led to new criteria for bacteriological quality, ammonia, and specific compounds like nonylphenol, carbaryl, chlorpyrifos, and diazinon. It also covers the reclassification of certain estuarine waters for shellfish propagation. The report emphasizes the importance of water quality modeling and coordination between the Department of Environmental Protection (DEP) and Water Management Districts (WMDs). Finally, it presents sediment quality evaluation for lakes, using threshold effects concentration (TEC) and probable effects concentration (PEC) to assess potential harm to sediment-dwelling organisms. Copper, lead, and zinc were found to have the most elevated concentrations in lake sediments. This document is a statewide water quality assessment for Florida, detailing findings on lake and groundwater sediment contaminants, surface water and groundwater trends, and designated use support in surface waters. It identifies specific pollutants of concern, such as metals (copper, lead, zinc) in lake sediments, and lists numerous water bodies impaired for dissolved oxygen, fecal coliform, mercury, and nutrients. The document outlines the Total Maximum Daily Load (TMDL) and Basin Management Action Plan (BMAP) programs, which are mechanisms for addressing these impairments. It details the status of adopted and pending BMAPs across various basins, specifying the parameters addressed and implementation status. The document does not contain specific project proposals, addresses, or developer information that would be directly actionable for contractors seeking specific work opportunities. Instead, it provides a broad overview of water quality issues and regulatory programs aimed at addressing them. This document is a comprehensive report on Florida's water quality, focusing on groundwater and surface water assessments from 2018. It details findings on various contaminants, including bacteria, salinity, metals, VOCs, SOCs, nitrate, and radionuclides, across different basins and water bodies. The report identifies areas with exceedances of primary drinking water Maximum Contaminant Levels (MCLs) and discusses potential sources and contributing factors. It also presents data on nutrient levels (nitrogen and phosphorus) and dissolved oxygen in springs and other surface waters, highlighting concerns related to algal growth and water quality degradation. The document does not contain specific project proposals, development applications, or contractor opportunities but provides extensive data on water quality conditions statewide. This document is a comprehensive water quality assessment for Florida, detailing various water bodies and their compliance with water quality standards. It lists specific lakes and water segments identified as impaired, along with the parameters causing the impairment (e.g., DO, Nutrients (TSI), Mercury (in fish tissue), Fecal Coliform, Lead, Iron, Copper, Silver, Thallium, Un-Ionized Ammonia, Turbidity). The document outlines the methodology for assessing water quality, including the Integrated Water Quality Assessment (IWR) and the Watershed Management Approach. It also details the classification of surface waters and the criteria for determining use support. There are no specific development projects, applicants, case numbers, or decisions mentioned in this excerpt. The focus is on existing water quality conditions and assessment methodologies. This document is a technical report detailing the methodology for evaluating water quality in Florida, including data exclusion criteria, biological assessment tools (SCI and BioRecon), and the evaluation of different use attainments (aquatic life, recreation, consumption, drinking water). It also discusses the use and risks associated with deep injection wells for wastewater disposal, including public perception and stakeholder engagement strategies. The document lists numerous entities involved in environmental monitoring and assessment across Florida. This document contains multiple unrelated items. One section discusses the technical aspects and public perception of deep injection wells (DIW) for wastewater disposal, noting that while the technology has improved, public concern exists regarding proximity to drinking water sources. It also details a specific project in Bushnell, Florida, where the city has not taken a formal stance on a landfill's plans to haul waste from Miami-Dade County or construct a leachate disposal injection well, deferring regulatory authority to the Florida Department of Environmental Protection (FDEP). Another section outlines the proposed budget for the Woodland Crossing Community Development District for Fiscal Year 2027, detailing revenues from assessments and expenditures for general administration and operations/maintenance. There is also information regarding water system workshops, sanitary survey inspections, and sampling requirements from the Florida Department of Environmental Protection's Central District Newsletter. [State Road (S.R.) 44 from west of I-75 to east of C.R. 229; case 452656-1] The Florida Department of Transportation (FDOT) plans to resurface State Road (S.R.) 44 from west of Interstate 75 (I-75) to east of County Road (C.R.) 229. The project includes rehabilitating the asphalt, filling sidewalk gaps, reconstructing pedestrian curb ramps to ADA standards, upgrading traffic signals and lighting, and evaluating driveway openings for modifications. The estimated costs are $1.6 million for design (ongoing, late 2026) and $8.1 million for construction (funded, summer 2027). [N. Morse Boulevard north of C 466] The Sumter County Board of County Commissioners (BOCC) is responding to requests from the Amenity Authority Committee (AAC) regarding speed limits and stop signs on N. Morse Boulevard. A study confirmed accidents involving golf carts are concentrated at intersections where vehicles and golf carts conflict. The AAC requested lowering the speed limit to 25 MPH and adding stop signs. The BOCC will not proceed with these requests, citing that N. Morse Boulevard is classified as a Minor Arterial Urban road, which requires continuous service and is not suitable for stop signs for speed control. Traffic data does not warrant lowering the speed limit, and speed was not indicated as a factor in accidents. The BOCC urges the AAC to implement lower-cost alternatives from a Kimley-Horn study to address intersection conflicts and improve multi-modal path safety. [1032 County RD 529, Lake Panasoffkee, FL 33538] The Sumter County Board of County Commissioners (BOCC) has received ongoing citizen complaints regarding odors and poor air quality from the Heart of Florida Landfill, operated by ACMS, Inc. at 1032 County RD 529, Lake Panasoffkee, FL 33538. Despite previous corrective actions and a report indicating violations were cured in December 2025, complaints persist. The County is pursuing legal action to compel compliance with permits and address public nuisance claims related to odor and air quality. ACMS, Inc. is demanded to immediately and consistently comply with Chapter 403, Florida Statutes, Rules 62-296.320 and 63-701.530, Florida Administrative Code, and odor/air quality provisions of Title V Air Permit No. 1190053-007-AV. [case SC2026-0440 (Supreme Court of Florida); 2022-CA-1562 (Lower Tribunal Case Number)] This document is a petition to the Supreme Court of Florida by the Florida PACE Funding Agency (Agency) seeking to compel 42 county tax collectors to perform their ministerial duty of collecting Agency assessments. The Agency obtained a $5 billion bond validation in 2022, which included a final judgment confirming its statewide authority and the tax collectors' duty to collect its assessments. This judgment, under section 75.09 of Florida Statutes, is 'forever conclusive' and cannot be challenged. However, tax collectors have refused to collect these assessments, leading to potential bond default. The Agency argues that ordinary legal remedies are inadequate and seeks extraordinary relief via writ to enforce the final judgment and prevent irreparable harm to the bond market. The document details the legal history, including previous court decisions affirming the Agency's position and the tax collectors' obligations. The core dispute centers on whether tax collectors have discretion to refuse collection based on arguments already rejected by the courts. [case SC2024-0652] This document is an appendix to an appellant's initial brief filed in the Supreme Court of Florida, case number SC2024-0652. It details an emergency motion for an order to show cause filed by the Florida PACE Funding Agency against various Florida tax collectors. The Agency seeks to hold the tax collectors in indirect civil contempt for failing to collect non-ad valorem assessments, which are used to secure revenue bonds for storm hardening and energy conservation improvements. The motion stems from a Final Judgment in 2022, which validated $5 billion in revenue bonds and declared the tax collectors' duty to collect these assessments as 'wholly ministerial.' This judgment was affirmed by the Florida Supreme Court in December 2025. The Agency argues that the continued refusal of certain tax collectors to perform this duty jeopardizes the Agency's ability to make bond payments, potentially leading to default. The document lists 42 tax collectors who are allegedly refusing to collect the assessments. The Agency is seeking sanctions, including per diem fines, remittance of outstanding amounts, and attorneys' fees. [case 2022-CA-1562] This document details a court's decision regarding the Florida PACE Funding Agency's (the Agency) revenue bonds. The court denied motions to invalidate a prior final judgment that authorized the Agency to issue up to $5,000,000,000 in bonds for qualifying improvements, including seawalls. The court affirmed its jurisdiction to validate the bonds and related matters, including the Agency's statewide authority and the ministerial duty of tax collectors to collect assessments. The decision stems from a bond validation proceeding initiated by the Agency, which was found to have complied with all statutory notice requirements. The court emphasized the finality of bond validation judgments and found the motions to be untimely and without legal merit. [case 2022-CA-1562 (Circuit Court); SC2024-0652, SC2024-0656, SC2024-0664, SC2024-0681 (Supreme Court)] This document details a legal dispute concerning a $5 billion bond validation for the Florida PACE Funding Agency (FPFA). The core issue was whether a motion for relief from the final judgment could be filed after the appeal period expired. The Supreme Court of Florida affirmed the circuit court's decision, ruling that Florida Rule of Civil Procedure 1.540 does not apply to bond validation proceedings due to the finality provisions in Chapter 75 of the Florida Statutes. The Court found that bond validation proceedings are special statutory proceedings where the statute's procedural rules take precedence over general civil procedure rules unless the rules specifically state otherwise. The Court also addressed jurisdictional arguments and affirmed that the appeals were properly before them. Dissenting opinions argued about the Court's jurisdiction and whether certain matters adjudicated in the bond validation were collateral and thus void. The document also lists various counties and tax collectors who were parties to the appeal, as well as amicus curiae briefs filed by other entities. This document details a legal dispute where numerous Florida Tax Collectors are refusing to collect non-ad valorem assessments certified by the Florida PACE Funding Agency (FPFA). The FPFA relies on these collections to repay bonds, and their failure to collect has led to financial strain and potential default. Despite a Florida Supreme Court decision affirming that motions to set aside judgments are not applicable in bond validation proceedings, many tax collectors maintain that the underlying issue of whether they are required to collect these assessments, and whether FPFA complied with statutory prerequisites, remains unresolved. Several tax collectors have explicitly declined settlement offers from FPFA, citing ongoing litigation and their interpretation of the Supreme Court's ruling as not compelling them to collect the assessments. Specific counties and tax collectors mentioned include Alachua, Baker, Bay, Bradford, Brevard, Collier, Columbia, DeSoto, Dixie, Duval, Escambia, Gadsden, Gilchrist, Glades, Hamilton, Hardee, Hendry, Hernando, Highlands, Hillsborough, Indian River, Jackson, Lake, Lee, Leon, Madison, Okaloosa, Okeechobee, Palm Beach, Pinellas, Putnam, Santa Rosa, Seminole, St. Johns, St. Lucie, Sumter, Taylor, Union, Volusia, Wakulla, Walton, and Washington. [216 South Monroe Street, Tallahassee, FL 32301 (Young Qualls, P.A.)] This document contains multiple letters from various county Tax Collectors in Florida, represented by Timothy R. Qualls of Young Qualls, P.A., to James C. Dinkins of Civil Forge Law. The letters, dated between January 13, 2026, and January 23, 2026, all state that the respective Tax Collector declines a proposed settlement from the Florida PACE Funding Agency (FPFA) regarding a bond validation action. The Tax Collectors maintain that the Florida Supreme Court's decision addressed only post-judgment finality and did not resolve substantive issues concerning the requirement for county Tax Collectors to collect PACE assessments, how these assessments should be administered, or FPFA's compliance with statutory prerequisites. They cite numerous trial court rulings that favored Tax Collectors in similar mandamus actions. The proposed settlement is deemed unacceptable as it would impose unsupported legal and operational obligations and expose the Tax Collectors to ongoing risk without adequate protections. [216 South Monroe Street, Tallahassee, FL 32301 (Young Qualls, P.A. office); Post Office Box 1833, Tallahassee, FL 32302-1833 (Young Qualls, P.A. reply to); Post Office Box 141148, Orlando, Florida 32814 (Civil Forge Law address); PO Box 1110, Tampa, FL 33601-1110 (Hillsborough County Attorney office); case 2022-CA-1562 (Leon County, Florida)] This document contains correspondence and court filings related to a legal dispute involving the Florida PACE Funding Agency (FPFA) and various County Tax Collectors regarding the collection of PACE assessments. Multiple Tax Collectors, including those from Gadsden, Volusia, and Hillsborough Counties, have declined settlement proposals from FPFA. The core of the dispute centers on whether Tax Collectors are legally obligated to collect PACE assessments, with Tax Collectors asserting that the Supreme Court's decision only addressed post-judgment finality and did not resolve these substantive issues. Hillsborough County's Tax Collector noted that their interlocal agreement with FPFA was terminated in December 2020 and a new one was entered into in February 2025, impacting the collection of assessments. A court order from February 3, 2026, in Leon County, Florida, directs 42 Tax Collectors to show cause why they should not be held in contempt for failing to comply with previous court judgments and mandates regarding the collection of PACE assessments. A hearing was scheduled for February 9, 2026. Subsequent filings indicate that FPFA has provided notice of compliance with this order, serving the relevant documents on counsel for the Tax Collectors. [101 E. College Avenue, 5th Floor, Tallahassee, FL 32301 (Law Offices of Lawson Huck Gonzalez, PLLC); 215 South Monroe Street, Suite 601, Tallahassee, Florida 32301 (Gunster, Yoakley & Stewart, P. A.); 401 E. Jackson Street, Suite 1500, Tampa, Florida 33602 (Gunster, Yoakley & Stewart, P. A.); 107 W. College Avenue, Tallahassee, Florida 32301 (Kutak Rock LLP); 301 S. Monroe Street, Room 202, Tallahassee, Florida 32301-1861 (Leon County Attorney's Office); 200 East Broward Boulevard, Suite 1900, Fort Lauderdale, Florida 33301 (Weiss Serota Helfman Cole & Bierman, P.L.); One Independent Drive, Suite 1300, Jacksonville, FL 32201 (Foley & Lardner LLP); 106 East College Avenue, Suite 900, Tallahassee, FL 32301-7732 (Foley & Lardner LLP); 2300 Virginia Avenue, Fort Pierce, Florida 34982 (St. Lucie County); 216 South Monroe Street, Tallahassee, Florida 32301 (Young Qualls, P.A.); 1785 Thomasville Road, Tallahassee, FL 32303-5707 (Webster + Baptiste, PLLC); Gateway Blvd. Ste. 201-I, Fernandina Beach, Florida 32034 (Jacobs Scholz & Wyler, LLC); 2725 Judge Fran Jamieson Way, C-308, Viera, Florida 32940 (Brevard County Attorney); 3299 East Tamiami Trail, Suite 800, Naples, Florida 34112-5749 (Collier County Attorney’s Office); 601 E Kennedy Blvd, Tampa, FL 33602-4932 (Hillsborough County Attorney's Office); 117 W Duval St Ste 480, Jacksonville, FL 32202-5721 (Office of General Counsel); P.O. Box 985, Tavares, Florida 32778 (Brionez + Brionez, P.A.); Leon County Courthouse, 301 S. Monroe Street, Suite 475, Tallahassee, Florida 32301 (State Attorney’s Office); Office of the State Attorney, 110 NW 1 Ave, Suite 5000, Ocala, Florida 34475 (State Attorney for the Fifth Judicial Circuit); Office of the State Attorney, P.O. Box 17500, Clearwater, Florida 33765-0500 (State Attorney for the Sixth Judicial Circuit); 251 N. Ridgewood Avenue, Daytona Beach, Florida 32114 (Office of Seventh Circuit State Attorney R.J. Larizza); Office of State Attorney, 415 N. Orange Avenue, Orlando, Florida 32801 (Office of Andrew A. Bain, State Attorney, Ninth Judicial Circuit); 120 W. University Avenue, Gainesville, Florida 32601 (State Attorney for the Eighth Judicial Circuit); 315 Court Street, Sixth Floor, Clearwater, Florida 33756 (Pinellas County Attorney’s Office); 20 North Main Street, Suite 462, Brooksville, Florida 34601 (Hernando County Attorney); P.O. Box 398, Fort Myers, Florida 33902-0398 (Lee County Attorney’s Office); 300 N Dixie Hwy, Floor 3, West Palm Beach, Florida 33401-4630 (Palm Beach County Attorney’s Office); 123 W. Indiana Avenue, DeLand, Florida 32720 (Volusia County); 301 North Olive Avenue, 3rd Floor, West Palm Beach, FL 33401 (Palm Beach County Tax Collector); P.O. Box 2016, Bartow, Florida 33831 (Polk County Tax Collector); Polk County Attorney’s Office, PO Box 9005, Drawer AT01, Bartow, Florida 33831-9005 (Polk County Attorney’s Office); Lee County Tax Collector’s Office, 2480 Thompson Street, 4th Floor, Fort Myers, Florida 33901 (Lee County Tax Collector); 20 South Broad Street, Brooksville, Florida 34601 (Hogan Law Firm); PO Box 5325, Vero Beach, FL 32961-5325 (Robert C. Nall, P.A.); P.O. Box 1110, Tampa, Florida 33601-1110 (Hillsborough County Tax Collector); 2300 Virginia Avenue, Fort Pierce, Florida 34982 (St. Lucie County); 216 South Monroe Street, Tallahassee, Florida 32301 (Young Qualls, P.A.); 1785 Thomasville Road, Tallahassee, FL 32303-5707 (Webster + Baptiste, PLLC); Gateway Blvd. Ste. 201-I, Fernandina Beach, Florida 32034 (Jacobs Scholz & Wyler, LLC); 2725 Judge Fran Jamieson Way, C-308, Viera, Florida 32940 (Brevard County Attorney); 3299 East Tamiami Trail, Suite 800, Naples, Florida 34112-5749 (Collier County Attorney’s Office); 840 W. 11th Street, Panama City, Florida 32401 (Bay County); P.O. Box 2340, LaBelle, Florida 33975 (Hendry County Attorney); P.O. Box 7800, Tavares, Florida 32778-7800 (Lake County Attorney’s Office); 201 S. Rosalind Avenue, 3rd Floor, Post Office Box 1393, Orlando, Florida 32802-1393 (Orange County); 123 W. Indiana Avenue, DeLand, Florida 32720 (Volusia County); 301 North Olive Avenue, 3rd Floor, West Palm Beach, FL 33401 (Palm Beach County Tax Collector); P.O. Box 2016, Bartow, Florida 33831 (Polk County Tax Collector); Polk County Attorney’s Office, PO Box 9005, Drawer AT01, Bartow, Florida 33831-9005 (Polk County Attorney’s Office); Lee County Tax Collector’s Office, 2480 Thompson Street, 4th Floor, Fort Myers, Florida 33901 (Lee County Tax Collector); 315 Court Street, Sixth Floor, Clearwater, Florida 33756 (Pinellas County Attorney’s Office); 20 South Broad Street, Brooksville, Florida 34601 (Hogan Law Firm); PO Box 5325, Vero Beach, FL 32961-5325 (Robert C. Nall, P.A.); 601 E Kennedy Blvd, Tampa, FL 33602-4932 (Hillsborough County Attorney's Office); 117 W Duval St Ste 480, Jacksonville, FL 32202-5721 (Office of General Counsel); P.O. Box 985, Tavares, Florida 32778 (Brionez + Brionez, P.A.); Leon County Courthouse, 301 S. Monroe Street, Suite 475, Tallahassee, Florida 32301 (State Attorney’s Office); Office of the State Attorney, 110 NW 1 Ave, Suite 5000, Ocala, Florida 34475 (State Attorney for the Fifth Judicial Circuit); Office of the State Attorney, P.O. Box 17500, Clearwater, Florida 33765-0500 (State Attorney for the Sixth Judicial Circuit); 251 N. Ridgewood Avenue, Daytona Beach, Florida 32114 (Office of Seventh Circuit State Attorney R.J. Larizza); Office of State Attorney, 415 N. Orange Avenue, Orlando, Florida 32801 (Office of Andrew A. Bain, State Attorney, Ninth Judicial Circuit); 120 W. University Avenue, Gainesville, Florida 32601 (State Attorney for the Eighth Judicial Circuit).; case 2022-CA-1562] This document is a legal filing related to the Florida PACE Funding Agency (FPFA) and outstanding assessments. It details a court case (Case No. 2022-CA-1562) in the Second Judicial Circuit, Leon County, Florida, where FPFA is the plaintiff and the State of Florida is a defendant. The filing includes a Schedule of Outstanding Assessments as of January 28, 2026, listing various county tax collectors and the total outstanding assessment amounts for their respective counties. It also includes responses from Tax Collectors (Hillsborough, Lake, Brevard, Indian River Counties) arguing against contempt charges and asserting lack of jurisdiction and legal duty to collect certain assessments. The core of the dispute revolves around the authority of FPFA to impose non-ad valorem assessments statewide and the requirement for local government authorization (ordinances, resolutions, interlocal agreements) for PACE programs to operate and for assessments to be placed on tax rolls. Several court decisions and legislative clarifications are cited to support the Tax Collectors' positions. [case Multiple case numbers referenced across various jurisdictions, including Case No. 5D2023-3366 (Volusia County), Case No. 2023CA000675 (Gadsden County), and others related to Lake, Brevard, and Indian River Counties.] This document details legal proceedings and disputes involving the Florida PACE Funding Agency (FPFA) and various Florida Tax Collectors. The core issue revolves around FPFA's authority to operate its Property Assessed Clean Energy (PACE) program and collect assessments, particularly concerning whether local governments have authorized FPFA's operations within their jurisdictions. Several tax collectors (Lake, Brevard, Indian River, Volusia, Gadsden) are involved in legal actions against FPFA, arguing that FPFA lacks proper authorization and is attempting to operate outside its legal scope. Key legal arguments include challenges to FPFA's statewide jurisdiction claims, the necessity of Interlocal Agreements (ILAs) for FPFA to operate, and the lack of personal jurisdiction over tax collectors in certain court proceedings. In Lake County, a default final judgment was entered against FPFA. In Brevard County, FPFA's authorization was rescinded for residential properties, and negotiations for a new agreement ceased due to FPFA's claims of statewide authority. Indian River County has never authorized FPFA. In Volusia and Gadsden Counties, petitions for writs of mandamus filed by FPFA to compel tax collectors to collect assessments were denied, with courts citing lack of clear legal right, insufficient evidence of irreparable harm, or the discretionary nature of the tax collector's duties. The document highlights ongoing litigation and differing interpretations of Florida statutes governing PACE programs and local government authority. [case No. 1D2024-2301 (Appeal); 2022-CA-1562 (Bond Validation); 20-2023-CA-000675-AXXX-XX (Gadsden County Mandamus)] This document details a legal dispute and bond validation concerning the Florida PACE Funding Agency (FPFA). The FPFA, a public body corporate and politic created by interlocal agreement between Flagler County and the City of Kissimmee, sought to issue up to $5,000,000,000 in revenue bonds for a qualifying improvement finance program. This program allows property owners to finance energy efficiency, renewable energy, and wind resistance improvements through non-ad valorem assessments. A key legal issue involved the FPFA's authority to operate statewide and independently, particularly in Gadsden County, without specific interlocal agreements with each county. The Gadsden County Tax Collector argued that FPFA lacked the independent authority to compel him to collect these assessments without such agreements, citing concerns about consumer protection and proper notice to homeowners. The court ultimately dismissed the petition for writ of mandamus, finding that the Tax Collector had discretion and that FPFA's claim to statewide authority without local interlocal agreements was not established. Separately, a bond validation case in Leon County affirmed the FPFA's authority to issue bonds up to $5,000,000,000 for qualifying improvements, finding it was a separate legal entity empowered by general law and the Charter Agreement to act independently and serve populations throughout Florida. The court determined that seawalls qualify as wind resistance improvements. The document also outlines the legal framework, notice requirements, and collection methods for non-ad valorem assessments under Florida statutes. [case 2022-CA-1562 (Bond Validation Case); 2023-CA-002974 (Lake County Lawsuit)] The Florida PACE Funding Agency (FPFA) issued revenue bonds not to exceed $5,000,000,000 for qualifying improvements, including seawalls. This was validated by the Circuit Court for Leon County, Florida, on October 6, 2022. Subsequently, Lake County and its Tax Collector filed a lawsuit (Case No. 2023-CA-002974) against FPFA, seeking declaratory and injunctive relief. The court granted a default final judgment against FPFA, enjoining it from operating its PACE program in Lake County without an interlocal agreement with the County and prohibiting the Tax Collector from collecting assessments for PACE loans not meeting statutory requirements. The court found that FPFA's prior bond validation judgment did not grant it authority to operate in Lake County without local consent and that collateral issues decided in that proceeding were beyond the court's jurisdiction. [400 South Street, Titusville, Brevard County, Florida; case 2026-CA- ------ (Brevard County Circuit Court)] This document details a legal dispute and related resolutions concerning the Property Assessed Clean Energy (PACE) program in Brevard County, Florida. Initially, Brevard County established a PACE program in 2018 through Resolution 18-040, participating in programs managed by the Florida Green Finance Authority, Florida PACE Funding Agency, Green Corridor PACE District, and Florida Resiliency and Energy District. However, in 2022, Brevard County partially rescinded Resolution 18-040 via Resolution 22-067, terminating the PACE program for single-family residential properties and nonprofit organizations due to concerns about consumer protections and oversight. This action led to a legal conflict, particularly involving the Florida PACE Funding Agency (FPFA), regarding the Tax Collector's obligation to place PACE assessments on the tax rolls. FPFA asserted authority based on a bond validation proceeding, which the Brevard County Tax Collector argued was improperly used to bypass local authorization requirements. The Tax Collector initiated a lawsuit seeking declaratory and injunctive relief to prevent FPFA from operating and imposing assessments without Brevard County's express consent, citing the county's termination of its participation and the home rule authority of counties. The document also references ongoing litigation in Lake County involving FPFA and the Lake County Tax Collector concerning similar issues of unauthorized operations. [case 2022-CA-1562 (Second Judicial Circuit, Leon County, Florida)] This document details legal proceedings and affidavits concerning the Florida PACE Funding Agency (FPFA) and its ability to collect assessments on tax rolls in various Florida counties. Brevard County, through its Tax Collector, is seeking a declaratory judgment and injunctive relief to prevent FPFA from operating and collecting assessments without express county authorization, citing violations of state law and county ordinances. Affidavits from the Tax Collectors of Brevard County, Indian River County, Lee County, and Palm Beach County outline their positions. Brevard County rescinded its prior authorization for FPFA's PACE program for single-family residential properties and nonprofit organizations due to lack of consumer protection and oversight. Indian River County states it has never authorized FPFA's PACE programs. Lee County and Palm Beach County Tax Collectors are asserting that FPFA has not met statutory prerequisites for collection via the Uniform Method of Collection, including proper notice to property owners, and that they cannot lawfully place assessments on tax rolls without such compliance. Multiple tax collectors are contesting the jurisdiction of the court in Leon County to compel them to act, arguing they were not parties to the original bond validation proceeding and that such matters should be handled in their respective county courts. Public comment is not explicitly detailed, but the sentiment from the Tax Collectors and counties indicates significant opposition to FPFA's collection demands without proper authorization and adherence to statutory requirements.
- Board:
- Board of County Commissioners Regular Meeting
- Date:
- 2026-04-28
- Type:
- Packet
- Decision:
- Approved
- Address:
- 601 C-478A
- Applicant:
- Timothy and Vivian Himes
April 21, 2026 Workshop Agenda
This document is a workshop agenda for the Board of Sumter County Commissioners meeting on April 21, 2026. It outlines several agenda items, including a Public Forum, Sheriff's Office Partnership, Sumter County AI Use Improvements Update, Sumter County Fire Assessment Program, and SECO Street Lighting Resolution. Several documents are listed as supporting materials for these agenda items, including various agreements, reports, and quotes related to law enforcement, AI usage, fire assessment, and street lighting. The meeting is scheduled for 6:00 PM at 7375 Powell Road, Wildwood, FL 34785. No decisions are listed as being made at this workshop, and the agenda items are for information or direction.
- Board:
- Board of County Commissioners Workshop
- Date:
- 2026-04-21
- Type:
- Agenda
- Address:
- 7375 Powell Road, Wildwood, FL 34785
April 21, 2026 Workshop Agenda packet 2026-04-21
The Sumter County Board of County Commissioners (BOCC) and the School Board of Sumter County are entering into a School Safety Program Agreement with the Sumter County Sheriff's Office. This agreement, effective October 1, 2026, through September 30, 2027, assigns 15,236 hours of School Resource Officer (SRO) time. The BOCC will invoice the School Board at $46.58 per hour for these hours, with any hours exceeding the allotment billed at $93.16 per hour. The agreement covers SRO services at multiple elementary, middle, and high schools, as well as an academy, located throughout Sumter County. The BOCC also funds a Sergeant position for SRO oversight. This agreement nullifies prior agreements regarding SROs and is in response to the Marjory Stoneman Douglas High School Public Safety Act. The Sumter County Board of County Commissioners (BOCC) and the Sumter County Sheriff's Office are entering into a School Safety Program Agreement with The Villages Charter School, Inc. This agreement, effective April 28, 2026, through September 30, 2027, assigns 8,500 hours of School Resource Officer (SRO) time. The BOCC will invoice the Charter School at $46.58 per hour for these hours, with any hours exceeding the allotment billed at $93.16 per hour. The agreement covers SRO services at various campuses of The Villages Charter School, including elementary, middle, and high school locations, and floating SRO support. The BOCC also funds a Sergeant position for SRO oversight. This agreement nullifies prior agreements regarding SROs and is in response to the Marjory Stoneman Douglas High School Public Safety Act. [City of Coleman: 3502 E. Warm Springs Avenue, Coleman, FL 33521; Sheriff's Office: 7361 Powell Road, Wildwood, FL 34785; BOCC: 7375 Powell Road, Wildwood, FL 34785] The City of Coleman and the Sheriff of Sumter County, Florida, have entered into an Agreement for Law Enforcement Services, with concurrence from the Board of County Commissioners (BOCC). This agreement, effective October 1, 2024, through September 30, 2029, outlines the provision of law enforcement services by the Sumter County Sheriff within the City of Coleman. The Sheriff will provide one deputy for eighty-four (84) hours per two-week pay period, along with a Lieutenant or higher to administer the agreement. The City of Coleman will pay the BOCC an annual cost that includes replacement vehicle payments and use of the Coleman Annex, with monthly payments due on the 15th of each month. The annual cost for fiscal year 2024-2025 is $133,903, increasing annually to $150,709 by fiscal year 2028-2029. The agreement vests police powers in the Sheriff and deputies within Coleman and requires interagency coordination. The staff recommended approval. [City of Center Hill: P.O. Box 649, Center Hill, FL 33514; Sheriff's Office: 7361 Powell Road, Wildwood, FL 34785; BOCC: 7375 Powell Road, Wildwood, FL 34785] The City of Center Hill, the Sheriff of Sumter County, and the Sumter County Board of County Commissioners (BOCC) have entered into an Interlocal Agreement for Law Enforcement Services. This agreement, effective October 1, 2021, with a termination date of September 30, 2026, outlines the provision of law enforcement services by the Sumter County Sheriff within the City of Center Hill. The Sheriff will provide two (2) patrol deputies for twelve (12) consecutive hours each day, plus one (1) deputy with the rank of Lieutenant or higher to administer the agreement. The City of Center Hill will pay monthly to Sumter County one-twelfth (1/12) of the annual amount for these services. The agreement vests police powers in the Sheriff and deputies within Center Hill and requires interagency coordination. The staff recommended approval. [85 East Central Avenue, Webster, FL 33597 (City Manager's Office); 7361 Powell Road, Wildwood, FL 34785 (Sheriff's Office); 7375 Powell Road, Wildwood, FL 34785 (Sumter County Administrator's Office)] An interlocal agreement for law enforcement services between the City of Webster, Florida, and the Sheriff of Sumter County, Florida, with concurrence from Sumter County. The agreement outlines the provision of law enforcement services by the Sheriff's office within Webster's boundaries, including staffing levels, responsibilities, and financial considerations. The agreement is effective from October 1, 2021, and automatically renews annually until September 30, 2026, unless terminated. [PO Box 115, Bushnell, FL 33513 (City); 7361 Powell Road, Wildwood, FL 34785 (Sheriff); 7375 Powell Road, Wildwood, FL 34785 (Sumter County); case 01099217COB/SCSO] An amended and restated interlocal agreement for law enforcement services between the City of Bushnell, Florida, and Patrick 'Pat' Breeden as Sheriff of Sumter County, Florida, with approval from Sumter County. The agreement details the provision of law enforcement services by the Sheriff's office within Bushnell, including staffing increases, administrative roles, and financial terms. The agreement is effective from April 1, 2026, through September 30, 2029. Information regarding the Sumter County Fire Assessment Program, detailing the methodology for calculating fire assessment rates based on historical demand, demand availability, and hazardous class. The document outlines sample rates for various property types, including residential, commercial, industrial, institutional, and vacant land, for the fiscal year 2025-2026. It also includes a schedule for program implementation, with key dates for workshops, ordinance adoption, and certification of the assessment roll. District 7 evaluated options for street lighting, including purchasing existing SECO-owned poles and fixtures, removal, or conversion to solar. They ultimately decided to remain with SECO but are still inquiring about light brightness and placement. The analysis included cost comparisons for SECO's current service, a Helios Energy lease, Helios Energy direct purchase, and Renovo direct purchase over 20 and 30-year periods. District 7's existing agreements with SECO for area lighting involve SECO installing, owning, operating, and maintaining fixtures. Specific agreements detail the number and type of fixtures, such as 33 concrete poles with 100-watt Colonial fixtures for Unit 136, 14 concrete poles with 100-watt colonial fixtures for Unit 140, and 4 fluted poles with 100-watt acorn fixtures for Pilar Villas. These agreements were established in 2008 and are for a five-year term, renewable thereafter. [case 80133089] Multiple permits issued for decorative colonial light pole installation and repair. Projects are located across various coordinates within Village Co. and are associated with case number 80133089. [80133089; case 80133089] Multiple permits issued for decorative colonial fix high pressure light poles. The projects are located across various coordinates within Village Co, with case number 80133089. Dates of record range from 2006-03-03 to 2011-12-21. All entries indicate existing underground utilities and concrete bases. [case 80133089, 80258630] This document contains multiple records related to lighting projects within Village Community Development District No. 7. The records detail the installation and specifications of decorative and area lights, including colonial and acorn fixtures, with varying dates of approval and installation between 2004 and 2022. The projects involve existing underground utilities and concrete bases. The document also discusses the regulatory framework for lighting in The Villages, referencing IESNA standards and Sumter County Code, and outlines a current Solar Street Lighting Project in the RFP phase with an estimated completion in 2025. The Engineer's Report from December 2005/January 2006 details the overall development of The Villages, including acreage and construction summaries across different components. [Northeast corner of Sumter County, Florida, north of County Road 466-A and west of the Lake/Sumter County lines.; case Sumter County, Florida Ordinance No. 04-35 (District creation); Sumter County, Florida Ordinance No. 05-32 (District boundary amendment).] Village Community Development District No. 7, located in the northeast corner of Sumter County, Florida, is undergoing development. The District encompasses 976.0 acres, with approximately 948 acres within the Villages of Sumter DRI. An additional 28 acres, designated as the 'Additional Area' (Unit 172), is intended for approximately 134 residential lots and is anticipated to be incorporated into the Villages of Sumter DRI by December 31, 2007, via a Notice of Proposed Change (NOPC). The development is planned as a Planned Unit Development (PUD) and will include 3,603 standard building lots and 1,142 villa building lots, totaling 4,745 lots. Infrastructure development, including roads, drainage, water, wastewater, and irrigation systems, is underway and funded by the District, the Developer (The Villages of Lake-Sumter, Inc.), North Sumter Utility Company (NSU), and The Villages Water Conservation Authority (VWCA). Construction contracts for master grading, stormwater, and roadway improvements are in place. All project improvements are scheduled for completion by June 2008. The total estimated construction cost for all project improvements is $125,238,053, with $81,339,399 funded by the District, $24,297,796 by the Developer, and $19,600,858 by utilities.
- Board:
- Board of County Commissioners Workshop
- Date:
- 2026-04-21
- Type:
- Packet
- Decision:
- Approved (implied by agreement execution)
- Address:
- City of Coleman: 3502 E. Warm Springs Avenue, Coleman, FL 33521; Sheriff's Office: 7361 Powell Road, Wildwood, FL 34785; BOCC: 7375 Powell Road, Wildwood, FL 34785
- Applicant:
- School Board of Sumter County, Sumter County Sheriff's Office, Board of County Commissioners of Sumter County
April 14, 2026 Regular Meeting Agenda
The Board of County Commissioners of Sumter County, Florida, will hold a Public Hearing on April 14, 2026, at 6:00 PM, at the Everglades Regional Recreation Center, 5497 Marsh Bend Trail, Grand Canyon Room, The Villages, FL 32163. The agenda includes a Quasi-Judicial Public Hearing for a rezoning request (Case Number ZON25-000013) for approximately 51.6 acres from General Agriculture Minimum 10 Acres with Conventional Housing (A10C) and Rural Residential 5 Acres with Conventional Housing (RR5C) to a Planned Unit Development (PUD) for a Conservation Subdivision. The Planning and Zoning Special Master and Staff recommend approval, with a note that Staff recommends retaining conditions removed by the Planning and Zoning Special Master. Documents related to this item include an Executive Summary, PZSM Order, Staff Report, Application, Public Input, Proof of Publication, Resolution, and Request. Another item is a Public Hearing to consider the Vacation of a Portion of Plum Street adjacent to Parcels J13B203 and J13B204 (Case Number SUB26-000005), with Staff recommending approval. Documents for this item include an Executive Summary, Application, Proof of Publication, Deed, and Exhibit A Survey and Description. The agenda also includes various reports and input items, including proclamations and letters for information only. New Business includes action required items such as approving and executing a contract for Grant Assistance for the Affordable Housing (AH) Program, entering into an agreement with Culinary Ventures for Vending Machine Services, terminating a cooperation agreement with Habitat for Humanity, and approving an Individual Project Order (IPO) 31 for the Lake Panasoffkee Pedestrian Routing Study. Financial items include budget amendments, purchase order approvals, and change orders. General Items for Consideration include a Limited Certificate of Public Convenience and Necessity (COPCN) for HCA Florida Ocala Hospital and a Revised Waiver of Fines for Code Enforcement Liens Policy. The meeting will adjourn after these items.
- Board:
- Board of County Commissioners Regular Meeting
- Date:
- 2026-04-14
- Type:
- Agenda
- Decision:
- Staff Recommends Approval; however, with Different Conditions - Staff Recommends the Conditions Removed by the Planning and Zoning Special Master be Retained.
- Address:
- 5497 Marsh Bend Trail, Grand Canyon Room, The Villages, FL 32163
- Applicant:
- Williams
April 14, 2026 Regular Meeting Agenda packet 2026-04-14
[North W C 48 and West of CR 316A, Bushnell Area; case ZON25-000013] The Board of Sumter County Commissioners is considering a rezoning request for Robert Williams (Case Number ZON25-000013) to develop 51.6 acres into a Conservation Subdivision. The property is currently zoned A10C and RR5C and has an Agriculture Future Land Use. The proposed change is to PUD zoning. The Planning and Zoning Special Master and Staff recommend approval, with staff advocating for the retention of conditions that were initially removed by the Special Master. These conditions relate to land preservation, lot size and density adjustments, traffic impact analysis, and the cessation of prior special exception and conditional use permits. A separate item involves a public hearing to consider the vacation of a portion of Plum Street adjacent to Parcels J13B203 and J13B204, with staff recommending approval. [North W C 48 and West of CR 316A, Bushnell Area; case ZON25-000013] Rezoning application ZON25-000013 for 51.6 acres from A10C and RR5C to PUD for development as a Conservation Subdivision. The Board of County Commissioners approved the rezoning on April 14, 2026, subject to conditions. A public hearing for the Board of County Commissioners is scheduled for March 24, 2026. [Plum Street adjacent to Parcels J13B203 and J13B204; case SUB26-000005] Application SUB26-000005 to vacate a portion of Plum Street adjacent to parcels J13B203 and J13B204. Staff recommended approval. The Board of County Commissioners meeting was scheduled for April 14, 2026. [J13B203 (for Ford), J13B204 (for Gavin)] Sumter County is conveying portions of Plum Street to two different grantees. The first conveyance is to Thomas Ford, Jr. and Stacy D. Ford, involving the East ½ of Plum Street west of Block 89 and the East ½ of a portion of Plum Street east of vacated Guava Street, north of Block 89. The second conveyance is to Antonio D. Gavin and Tiffany Gavin, involving the West ½ of Plum Street east of Block 90 and the West ½ of a portion of Plum Street west of vacated Guava Street, north of Block 90. Both deeds are dated in 2026 and involve a nominal consideration of $10.00 plus other valuable considerations. The legal descriptions reference a plat recorded in Plat Book 1, Page 20, Public Records of Sumter County, Florida. Sumter County Board of County Commissioners issued a proclamation honoring the South Sumter Wolfpack Pop Warner Football Program for their athletic achievements, resilience, and community engagement. The program has overcome challenges like COVID-19 and declining participation, rebuilding to achieve success in recent seasons, including multiple playoff appearances and Conference Championships. The 8U team reached the State Semi-finals in the 2025 season. Sumter County Board of County Commissioners proclaimed the week of April 12-18, 2026, as Public Safety Telecommunicators Week. The proclamation recognizes the critical role of telecommunicators in emergency response, their contribution to public safety, and their professionalism. Sumter County Board of County Commissioners proclaimed the week of April 12-18, 2026, as Animal Care and Control Appreciation Week. The proclamation commends Animal Control Officers and Animal Services Staff for their dedicated service in protecting the health and welfare of animals and the public, including responding to dangerous animals and abuse reports. Sumter County Board of County Commissioners proclaimed April 18, 2026, as Earth Day. The proclamation highlights the importance of environmental stewardship and environmental education, noting CEMEX USA's Center Hill Mine's 17th Annual Earth Day Celebration on April 18, 2026, in partnership with the Sumter School District and other community organizations. [City of Bushnell] Sumter County Board of County Commissioners is writing to the Florida Department of Environmental Protection (FDEP) regarding the Heart of Florida Landfill's planned treated leachate disposal injection well in Bushnell. The County acknowledges FDEP's primacy in permitting and regulatory oversight but expresses concern due to a lack of independent information, which has created opposition. The County requests FDEP to confirm the disposal will not endanger public water supply and to provide an educational session on the well's design, construction, monitoring, and intervention protocols. They offer to host this session on June 2 or June 16, 2026, prior to the application to convert the exploratory well. [9641 CR 235, Wildwood, Florida] The National Park Service officially listed the Community of Royal Historic District, located at 9641 CR 235, Wildwood, Florida, in the National Register of Historic Places on February 26, 2026. This notification is for Sumter County. The Seminole County Board of County Commissioners is responding to Sumter County regarding a Medical Examiner agreement. Seminole County clarifies it is in District 24, not District 5, and intends to align with the current agreement until its conclusion in 2029. They are proceeding with plans to establish their own medical examiner's facility and do not anticipate renewing the agreement. [Leesburg, Florida] The International Lineman's Museum & Hall of Fame is establishing a permanent Memorial Garden at its new location in Leesburg, Florida, in partnership with the Fallen Linemen's Organization. The garden will honor linemen who keep communities powered, especially during storms and emergencies. They are inviting Sumter County departments to be represented and to share the opportunity with their team members to recognize individuals they have worked with. The Florida Development Finance Corporation (FDFC) Annual Report for Fiscal Year 2024-2025 details its role in promoting Florida's economic development through bond issuance and financing. In FY 2024-2025, FDFC facilitated over $2.6 billion in tax-exempt, taxable, and private activity bonds across thirteen projects in sectors including healthcare, solid waste, not-for-profits, transportation, charter schools, and private schools. Additionally, FDFC issued a record $292 million in Commercial Property Assessed Clean Energy (C-PACE) financing for ten projects such as hotels, self-storage, multi-family housing, mixed-use, senior housing, data centers, and medical facilities. [156 Tuskawilla Road, Suite 2340, Winter Springs, Florida 32708] The Florida Development Finance Corporation (FDFC) facilitated $2,640,646,826 in 13 new money bonds and $292,435,233 in 10 taxable C-PACE bonds for the fiscal year ending June 30, 2025. The new money bonds included financing for 3 transportation facilities, 4 private schools, 3 charter schools, 1 not-for-profit, 1 healthcare, and 1 solid waste bond. The C-PACE program provides financing for energy efficiency, renewable energy, and wind hardening projects for commercial, industrial, multifamily, and nonprofit properties. The FDFC's revenues are generated by fees charged for bond issuance, which can be impacted by economic conditions. The FDFC's financial statements for the year ended June 30, 2025, show total assets of $14,560,596 and total liabilities of $685,032, resulting in net position of $13,875,564. The FDFC earned $1,630,917 in conduit debt application and issuance fees and $1,127,547 in PACE program fees. [case 2025-CA-000384] This document is a financial statement for the Florida Development Finance Corporation (FDFC) for the year ending June 30, 2025. It details FDFC's accounting policies, capital assets, related party transactions, leases, and conduit debt issuances. The document also includes an independent auditor's report on internal control and compliance. Additionally, it contains correspondence regarding a cybersecurity grant awarded to Sumter County, a discussion on county ordinance authority related to state environmental regulations, and a court order staying proceedings in a case involving AQ OLD MILL, LLC and other defendants. [case 2025CA000466] This document pertains to a foreclosure case initiated by Carrington Mortgage Services, LLC against Wendell L. Wyatt, Marta Wyatt, and others. The case involves a motion for summary final judgment of foreclosure and for an award of attorneys' fees and costs. A hearing is scheduled for June 2, 2026, to address this motion. The underlying debt and mortgage were executed around April 30, 2018, with a default occurring on August 1, 2024. The plaintiff claims $76,947.07 is due on the principal. [7223 SW 55th Street, Bushnell, FL 33513; case 8:26-ap-00067-RCT] This document details a legal dispute concerning the validity of a mortgage and a settlement agreement related to a 68.57-acre property in Sumter County, Florida. The Debtor, Skytop Ranch, LLC, filed for Chapter 11 bankruptcy, challenging Wells Fargo's lien. The core issues involve a mortgage with an incorrect legal description (approximately 3 acres in Oxford, Florida, instead of the 68.57-acre property) and an incorrect borrower name ('Susan J. Hess and Spencer Hess Wife and Husband' instead of Skytop, LLC). A settlement agreement was allegedly reached on April 28, 2025, with a payment deadline of December 31, 2025, and a surrender deadline of January 15, 2026. However, the settlement is contested on grounds including lack of probate court authorization for the sale of estate property, questionable authority of signatories, absence of legal counsel for defendants, and unconscionably broad releases. Wells Fargo filed a motion for entry of consent judgment on January 15, 2026, to reform the mortgage, but it has not been entered. The Debtor-in-possession seeks to avoid Wells Fargo's lien under bankruptcy trustee powers, arguing it is ineffective against a hypothetical bona fide purchaser due to the defective recording. The case also involves potential liens from Sumter County Code Enforcement and the United States. The Debtor requests a determination that the mortgage is invalid, Wells Fargo has no secured claim, and the settlement/consent judgment is void. [3687 CR 405DW, Lake Panasoffkee, FL; Lots 10, Block 4, LAKE VIEW TERRACE, Sumter County, FL; case 2026-CC-000358; 2026-CC-000016; 8:26-bk-01144-RCT] This document contains multiple unrelated legal filings. The primary filings of interest to contractors appear to be foreclosure notices and a bankruptcy case dismissal. The foreclosure notices indicate ongoing legal actions by Sumter County, Florida, against various defendants for property at 3687 CR 405DW, Lake Panasoffkee, FL, and for Lots 10, Block 4, LAKE VIEW TERRACE, Sumter County, FL. The bankruptcy case involves Skytop Ranch, LLC (fka Skytop, LLC) and was dismissed and then reinstated. No specific construction projects or development plans are detailed in these filings. [9275 County Road 622, Bushnell, FL 33513; case 2025-CC-000345-AXMX] This document pertains to a foreclosure sale and subsequent assignment of bid for a property located at 9275 County Road 622, Bushnell, FL. The property was sold on March 19, 2026, for $100.00 to VAK MI00 FUND, LLC, which then assigned the bid to VAK M12 FUND LLC. The legal description includes Lots 8, 9, and 10, Block E, WITHLACOOCHEE HEIGHTS, along with an undivided interest in other lots and a 1982 Allard Doublewide Mobile Home. Sumter County Board of County Commissioners meeting on April 14, 2026, will consider a budget amendment (A-12) for FY 2025/2026. The amendment includes changes to the General Fund ($450,000), SHIP Program (Fund 121 - $350,605), SC Road Construction District Impact Fund (Fund 153 - $65,022), and Fire Impact Fee Fund (Fund 155 - $5,000). Specific allocations within these funds include recognition of FDEP planning grant revenue, Economic Development Strategic Plan, interlocal agreement with the City of Bushnell for law enforcement services, increased legal services for foreclosures, CivicPlus Doc Access and AI Editing Assistant, SHIP allocation payment, Central Parkway appraisal report, US301 & CR472 Duke relocation of light poles, C466 at C209 lighting invoice, and E County Road 462 appraisal report. Sumter County Board of County Commissioners meeting on April 14, 2026, will review a list of open purchase requisitions for FY 2025/2026, with staff recommending approval for requests of $25,000 and over. Notable requisitions include: Motorola Solutions, Inc. for Avigilon Access Control ($859,792.44) and P1 CAD Project ($823,401.37); GSB CONSTRUCTION AND DEVELOPME for Detention Center Water Heaters Conversion ($147,148.32); ATS WAYPOINT INC for HVAC Controls at Detention Center ($180,600.00); PERMA-FIX OF FLORIDA INC for Amnesty Day's ($150,000.00); SECO ENERGY for C 466 and CR 209 Lighting ($41,921.18); INFRASTRUCTURE CONSULTING & EN for Task Order #5 - C 466 at US 301 Intersection Alternative Study ($28,878.75); KIMLEY-HORN AND ASSOC, INC for IPO #31 - Lake Panasoffkee Pedestrian Routing Study ($35,300.00); LEVEL 3 COMMUNICATIONS LLC for Lumen Services for the Back-Up 911 Center in Bushnell ($32,522.41); ECHONOUS INC for Kosmos Ultrasound Probe Devices ($26,200.00); MARK COOK BUILDERS, INC for New Supervisor of Elections Facility ($136,065.83); and ATLANTIC PIPE SERVICES LLC for Storm Pipe Repair ($27,960.00). Sumter County Board of County Commissioners meeting on April 14, 2026, will consider a change order to Purchase Order No. 9128386 for Ernie Morris Enterprises, increasing the amount by $64,474.44 for furniture at the New Service Center. The original purchase order total was $508,985.60, and the new total will be $573,460.04. The funding source is the Capital Outlay Reserve Fund. [Various locations around the county; case Purchase Order No. 9127645] Sumter County Board of County Commissioners approved a change order to Purchase Order No. 9127645 for Morrison Property Service, increasing the contract by $75,000.00 for additional tree work services as needed throughout the county. The meeting was on 4/14/2026. [J04E006] Sumter County Board of County Commissioners staff recommends approval to declare Parcel J04E006, a 0.085-acre property with an assessed value of $27,970.00, as surplus and list it for sale with Smith and Smith Realty. The property was previously involved in a code case foreclosure and has been cleaned by public works. The meeting was on 4/14/2026. Sumter County Board of County Commissioners staff recommends approval for inventory transactions, including the disposal of an Air Compressor (Asset Tag # 02147) and several Laptops (Asset Tags # 05144, 05402, 05562, 06476, 07221), and the transfer of a Portable Fireflash Trainer (Asset Tag # 03145) to Inglis Fire Rescue. These actions are in accordance with the Capital Assets Policy. The meeting was on 4/14/2026. [920 Oak Avenue, Webster, FL 33597] Sumter County Board of County Commissioners staff recommends approval to execute a Contract for Grant Assistance under the Affordable Housing Program for Mr. and Mrs. Medina at 920 Oak Avenue, Webster, FL 33597. The grant amount is $175.00, leveraging Affordable Housing funds with SHIP funds for demolition/reconstruction. The meeting was on 4/14/2026. [Client Facility (locations to be determined); case ITB 026-0-2025] Sumter County Board of County Commissioners staff recommends approval to enter into an agreement with Culinary Ventures Vending for Vending Machine Services. The agreement is for an initial term of two years, starting 5/1/2026 and ending 4/30/2028, with automatic one-year renewals. The vendor will provide full-service beverage and snack vending. The commission rate is 13% on Net Sales. The meeting was on 4/14/2026. [Sumter County] Sumter County Board of County Commissioners staff recommends approval to terminate the Community Project Funding Cooperation Agreement with Habitat for Humanity of Lake-Sumter, Florida Inc. The agreement was for a grant application to fund affordable homeownership units. Habitat's project was not selected for funding by Congressman Webster's office. The termination date is 4/14/2026. The meeting was on 4/14/2026. [Lake Panasoffkee (from CR 414 to C 470); case IPO 31] Sumter County Board of County Commissioners staff recommends approval of Individual Project Order (IPO) 31 with Kimley-Horn and Associates, Inc. for the Lake Panasoffkee Pedestrian Routing Study. The study will assess pedestrian connection alternatives from CR 414 to the existing sidewalk on C 470. The contract effective date is 10/1/2024 and termination date is 9/30/2026, with a budget impact of $35,300.00. The meeting was on 4/14/2026. [case IPO 31] A pedestrian routing and feasibility study is being conducted by Kimley-Horn for Sumter County. The study will review existing conditions, identify alternative pedestrian routes between CR 436E and CR 414, and evaluate connections to CR 428 and C 470. It will also assess shared-use roadway designations if sidewalks are not feasible. The project includes cost estimates for three alternative routes. The total cost for these services is $35,300.00. [6131 Seven Mile Drive, Wildwood, FL 34785] HCA Florida Ocala Hospital (Marion Community Hospital, Inc.) has been issued a limited Certificate of Public Convenience and Necessity (COPCN) to operate inter-facility Advanced and Basic Life Support (ALS/BLS) Ambulance Transport Services. These services will originate from HCA Florida Trailwinds Village Emergency in Wildwood, FL. The COPCN is valid for 60 months, commencing October 1, 2024, and expiring September 30, 2030. Sumter County is revising its Waiver of Fines for Code Enforcement Liens Policy. The revision adds eligibility criteria preventing property owners from being eligible for waivers if they have other outstanding code violations or liens filed by other Sumter County jurisdictions. The policy outlines criteria for waiving fines for code enforcement liens after compliance, including administrative costs paid and no other outstanding violations. Waivers are considered by the Board of County Commissioners (BOCC) based on criteria such as the owner's history of violations and property acquisition circumstances. A 100% waiver is granted for properties acquired for County or State road rights-of-way. [LifeStream Behavioral Center at 2020 Tally Road, Leesburg, FL 34748] Sumter County has an approved Behavioral Health Transportation Plan for 2026, developed in accordance with Florida Statutes related to the Baker Act and Marchman Act. The plan establishes a framework for the safe and efficient transport of individuals requiring involuntary examination or treatment. It requires approval from the Sumter County Board of County Commissioners, LSF Health Systems, and the Florida Department of Children and Families. The plan outlines responsibilities for transporting adults and youth on involuntary Baker or Marchman Acts to LifeStream Behavioral Center, with specific provisions for individuals requiring additional medical care. The plan is a renewal of a previously established system. Sumter County is amending its Economic Development Targeted Business Industry Incentive Policy. The amendment proposes removing data center operations from the targeted industry recruitment process due to changes in state legislation. Currently, Sumter County incentivizes manufacturing, small and large fulfillment centers, data centers, and agribusiness research and development. The existing data center incentive requires a minimum capital construction investment of $10M, with payouts up to 2% of building capital investment, not exceeding $1,000,000 per year for three years ($3,000,000 total). [7375 Powell Road, Suite 100, Wildwood, FL 34785] The Sumter Public Library is adopting a Privacy Policy to protect customer information and data. The policy outlines how personal information, including library account details, transaction history, and computer/internet usage, is collected, used, protected, and shared. It states that personal data is used solely for library-related functions and is not sold or distributed for marketing. Information may be shared with authorized vendors for service provision or as required by law, including under court order or for public inspection under Florida Statutes Chapter 119. The policy also addresses data security measures and user rights for accessing, correcting, and deleting personal data.
- Board:
- Board of County Commissioners Regular Meeting
- Date:
- 2026-04-14
- Type:
- Packet
- Decision:
- Planning and Zoning Special Master and Staff Recommend Approval; however, with Different Conditions – Staff Recommends the Conditions Removed by the Planning and Zoning Special Master be Retained.
- Address:
- North W C 48 and West of CR 316A, Bushnell Area
- Applicant:
- Robert Williams
Mira los negocios reales detrás de estos números
Obtén los registros reales, con direcciones y directivos, gratis por 7 días. Sin tarjeta de crédito.
Comienza tu prueba gratis