Browse Miami-Dade County civic records
Every published record for Miami-Dade County, newest first. Filter by board, year, or industry to jump straight to the records you want, and page through to reach the full archive.
30,435 records
HCD SHIP LHAP FY AMENDMENT
This is a legislative matter, File Number 261484, a Resolution to amend the Local Housing Assistance Plan (LHAP) for the State Housing Initiatives Partnership (SHIP) program for fiscal years 2025-2026, 2026-2027, and 2027-2028. The amendment adds a required strategy for providing SHIP funds to mobile homeowners, as mandated by Senate Bill 594, which became effective July 1, 2026. The strategy may include relocation assistance, lot rental payments, and rehabilitation/emergency repairs for low- and moderate-income mobile homeowners countywide. The item was amended and forwarded with a favorable recommendation by the Housing Committee on 9/9/2026, with a vote of 4-0. The agenda date is 10/6/2026. The prime sponsor is Marleine Bastien, with co-sponsors Vicki L. Lopez, Kionne L. McGhee, and Raquel A. Regalado. The requester is Housing and Community Development. The document does not state a specific address, parcel, size, or dollar amount. The document does not state any public comment or stakeholder sentiment.
- Board:
- Housing Committee
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- Amended and forwarded with a favorable recommendation by the Housing Committee on 9/9/2026; pending BCC assignment for agenda date 10/6/2026.
- Applicant:
- Housing and Community Development (HCD); Prime Sponsor: Marleine Bastien; Co-Sponsors: Vicki L. Lopez, Kionne L. McGhee, Raquel A. Regalado
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 between Horizon Contractors, Inc. and Miami-Dade County for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street, extending the contract duration by 421 non-compensable calendar days. The project involves widening NW 84 Avenue from two to four lanes, including two dedicated transit lanes, drainage, roadway reconstruction, sidewalks, lighting, and related infrastructure. The extension is non-compensable and does not increase the contract amount. The adjusted contract duration is 1,201 calendar days. The original contract amount was $7,730,537.60. The Transportation Cmte forwarded the item to the BCC with a favorable recommendation on 9/9/2026. The agenda date is 10/6/2026.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- Forwarded to BCC with a favorable recommendation by Transportation Cmte on 9/9/2026; pending BCC action on 10/6/2026
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 between Horizon Contractors, Inc. and Miami-Dade County for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street (Project No. DB21-DTPW-04; Contract No. 20210035). The agreement increases contract duration by 421 non-compensable calendar days, with no change to contract price. The project involves widening NW 84 Avenue from two to four lanes, including two dedicated transit lanes, drainage, roadway reconstruction, sidewalks, lighting, and related infrastructure. The original contract was approved on January 17, 2023 (Resolution No. R-23-23) in the amount of $7,730,537.60 for a total term of 780 calendar days, including 720 days to substantial completion. The adjusted contract duration with this change order is 1,201 calendar days. The supplemental establishes a full and final release of any claims for additional compensation related to delays. The Transportation Cmte forwarded to BCC with a favorable recommendation on 9/9/2026. Agenda date is 10/6/2026. Status is Before the Board. Introduced 8/19/2026. Requester: Transportation and Public Works. Project is in Commission District 12, represented by Commissioner Juan Carlos Bermudez. Leo Salgueiro, DTPW Infrastructure Manager, is responsible for monitoring. No fiscal impact. No public comment sentiment is stated in the document.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- Transportation Cmte forwarded to BCC with a favorable recommendation on 9/9/2026; status is Before the Board; agenda date 10/6/2026
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 between Horizon Contractors, Inc. and Miami-Dade County for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street, extending contract duration by 421 non-compensable calendar days. The project involves widening NW 84 Avenue from two to four lanes, including two dedicated transit lanes, drainage, roadway reconstruction, sidewalks, lighting, and related infrastructure. The original contract amount was $7,730,537.60 with a total term of 780 calendar days; the adjusted contract duration is 1,201 calendar days. The extension is non-compensable and does not increase the contract amount. The Transportation Committee forwarded to the BCC with a favorable recommendation on 9/9/2026. Agenda date is 10/6/2026. The project is in Commission District 12, represented by Commissioner Juan Carlos Bermudez. Delays were due to conflicts with existing third-party utilities. The supplemental establishes a full and final release of any claims for additional compensation related to these delays. No public comment or stakeholder sentiment is stated in the document.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- Forwarded to BCC with a favorable recommendation by Transportation Committee on 9/9/2026; pending BCC approval on 10/6/2026
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 between Horizon Contractors, Inc. and Miami-Dade County for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street (Project No. DB21-DTPW-04; Contract No. 20210035), increasing contract duration by 421 non-compensable calendar days. The project widens NW 84 Avenue from two to four lanes, including two dedicated transit lanes, with drainage, roadway reconstruction, sidewalks, lighting, and related infrastructure. The original contract was approved January 17, 2023 (Resolution No. R-23-23) in the amount of $7,730,537.60 for a total term of 780 calendar days, including 720 days to substantial completion. The adjusted contract duration with this change order is 1,201 calendar days. The extension is non-compensable and does not increase the contract amount. The supplemental establishes a full and final release of any claims for additional compensation related to delays caused by third-party utility coordination. The Transportation Committee forwarded to the BCC with a favorable recommendation on 9/9/2026. The agenda date is 10/6/2026. The project is in Commission District 12, represented by Commissioner Juan Carlos Bermudez. No public comment sentiment is stated in the document.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- Forwarded to BCC with a favorable recommendation by Transportation Committee on 9/9/2026; pending BCC assignment; agenda date 10/6/2026
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 between Horizon Contractors, Inc. and Miami-Dade County for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street, extending contract duration by 421 non-compensable calendar days. The project widens NW 84 Avenue from two to four lanes, including two dedicated transit lanes, with drainage, roadway reconstruction, sidewalks, lighting, and related infrastructure. The extension is non-compensable with no increase to the contract amount. The adjusted contract duration is 1,201 calendar days. The supplemental establishes a full and final release of any claims for additional compensation related to delays caused by third-party utility coordination. The Transportation Cmte forwarded to BCC with a favorable recommendation on 9/9/2026. Agenda date is 10/6/2026. No public comment or stakeholder sentiment is stated.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- Forwarded to BCC with a favorable recommendation by Transportation Cmte on 9/9/2026; pending BCC assignment, agenda date 10/6/2026
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 between Horizon Contractors, Inc. and Miami-Dade County for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street (Project No. DB21-DTPW-04; Contract No. 20210035). The agreement increases contract duration by 421 non-compensable calendar days, with no change to contract price. The project involves widening NW 84 Avenue from two to four lanes, including two dedicated transit lanes. The original contract was approved on January 17, 2023 (Resolution No. R-23-23) in the amount of $7,730,537.60 for a total term of 780 calendar days. The adjusted contract duration with this change order is 1,201 calendar days. The extension is due to delays from third-party utility relocations. The item was forwarded to the Board of County Commissioners with a favorable recommendation by the Transportation Committee on September 9, 2026, and is scheduled for the Board agenda on October 6, 2026. The resolution also establishes a full and final release of any claims for additional compensation related to these delays. No public comment sentiment is stated in the document.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- Forwarded to BCC with a favorable recommendation by Transportation Committee on 9/9/2026; pending BCC approval on 10/6/2026
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 between Horizon Contractors, Inc. and Miami-Dade County for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street, extending contract duration by 421 non-compensable calendar days. The project involves widening NW 84 Avenue from two to four lanes, including two dedicated transit lanes, with drainage, roadway reconstruction, sidewalks, lighting, and related infrastructure. The original contract amount was $7,730,537.60 with a total term of 780 calendar days. The extension is non-compensable and does not increase the contract amount; adjusted contract duration is 1,201 calendar days. The supplemental establishes a full and final release of any claims for additional compensation related to delays. The project is in Commission District 12, represented by Commissioner Juan Carlos Bermudez. The Board approved the original design-build contract on January 17, 2023 (Resolution No. R-23-23). The resolution was introduced on 8/19/2026, assigned to the County Attorney on 8/20/2026, and is scheduled for agenda date 10/6/2026 as agenda item number 8N. Status is In Committee (Transportation Cmte). No public comment or stakeholder sentiment is stated in the document.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- Recommended for approval by staff; status is In Committee; final action not stated
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 between Horizon Contractors, Inc. and Miami-Dade County for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street, extending contract duration by 421 non-compensable calendar days. The project involves widening NW 84 Avenue from two to four lanes, including two dedicated transit lanes, drainage, roadway reconstruction, sidewalks, lighting, and related infrastructure. The original contract amount was $7,730,537.60 with a term of 780 calendar days; the adjusted contract duration is 1,201 calendar days. The extension is non-compensable and does not increase the contract amount. The delay was due to conflicts with existing third-party utilities. The supplemental establishes a full and final release of any claims for additional compensation related to these delays. The project is in Commission District 12. The Board approved the original contract on January 17, 2023 (Resolution No. R-23-23). The resolution was introduced on 8/19/2026, agenda date 10/6/2026, agenda item number 8N, status in committee. No public comment sentiment is stated in the document.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- Recommended for approval by staff; status: In Committee
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 between Horizon Contractors, Inc. and Miami-Dade County for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street, extending contract duration by 421 non-compensable calendar days. The project widens NW 84 Avenue from two to four lanes, including two dedicated transit lanes, with drainage, roadway reconstruction, sidewalks, lighting, and related infrastructure. The original contract was approved January 17, 2023 (Resolution No. R-23-23) in the amount of $7,730,537.60 for a total term of 780 calendar days. The adjusted contract duration with this change order is 1,201 calendar days. The extension is non-compensable and does not increase the contract amount. The supplemental establishes a full and final release of any claims for additional compensation related to delays caused by third-party utility coordination. The Transportation Cmte forwarded to BCC with a favorable recommendation on 9/9/2026. Agenda date is 10/6/2026. Status is Before the Board. No public comment or stakeholder sentiment is stated.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- Forwarded to BCC with a favorable recommendation
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 with Horizon Contractors, Inc. for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street, extending contract duration by 421 non-compensable calendar days. The project involves widening NW 84 Avenue from two to four lanes, including two dedicated transit lanes, drainage, roadway reconstruction, sidewalks, lighting, and related infrastructure. The extension is due to delays from third-party utility conflicts. The adjusted contract duration is 1,201 calendar days. No fiscal impact; contract amount remains $7,730,537.60. Status: In Committee. Agenda date 10/6/2026. Introduced 8/19/2026. No public comment sentiment stated.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- In Committee; recommended for approval by staff; final action not stated
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 between Horizon Contractors, Inc. and Miami-Dade County for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street, increasing contract duration by 421 non-compensable calendar days. The project involves widening NW 84 Avenue from two to four lanes, including two dedicated transit lanes, drainage, roadway reconstruction, sidewalks, lighting, and related infrastructure. The extension is non-compensable and does not increase the contract amount. The adjusted contract duration is 1,201 calendar days. The supplemental establishes a full and final release of any claims for additional compensation related to delays caused by third-party utility coordination. The Board approved the original design-build contract on January 17, 2023 (Resolution No. R-23-23) in the amount of $7,730,537.60 for a total term of 780 calendar days. The item was introduced on 8/19/2026, assigned to County Attorney on 8/20/2026, and scheduled for agenda date 10/6/2026 as agenda item number 8N. Status is In Committee, Transportation Cmte. No public comment or stakeholder sentiment is stated in the document.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- Pending (In Committee); recommended for approval by staff
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 between Horizon Contractors, Inc. and Miami-Dade County for design-build services for Roadway Improvements to NW 84 Avenue from NW 58 Street to NW 74 Street (Project No. DB21-DTPW-04; Contract No. 20210035), increasing contract duration by 421 non-compensable calendar days. The project is in Commission District 12. The original contract was approved on January 17, 2023 (Resolution No. R-23-23) in the amount of $7,730,537.60 for a total term of 780 calendar days, including 720 days to substantial completion. The adjusted contract duration with this change order is 1,201 calendar days. The extension is non-compensable and does not increase the contract amount. The supplemental establishes a full and final release of any claims for additional compensation related to delays caused by third-party utility relocations. Status is In Committee, agenda date 10/6/2026, introduced 8/19/2026. The project provides for widening NW 84 Avenue from NW 58 Street to NW 74 Street from two to four lanes, including two dedicated transit lanes to support bus service along Route 87, with drainage, roadway reconstruction, sidewalks, lighting, and related infrastructure.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- In Committee; recommendation is to approve
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 between Horizon Contractors, Inc. and Miami-Dade County for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street (Project No. DB21-DTPW-04; Contract No. 20210035), increasing contract duration by 421 non-compensable calendar days. The project involves widening NW 84 Avenue from NW 58 Street to NW 74 Street from two to four lanes, including two dedicated transit lanes, drainage, roadway reconstruction, sidewalks, lighting, and related infrastructure. The original contract amount was $7,730,537.60 with a total term of 780 calendar days. The adjusted contract duration is 1,201 calendar days. The extension is non-compensable and does not increase the contract amount. The supplemental establishes a full and final release of any claims for additional compensation related to delays. The project is in Commission District 12. The Board approved the original design-build contract on January 17, 2023 (Resolution No. R-23-23). The item was introduced on 8/19/2026, agenda date 10/6/2026, agenda item number 8N, status in committee. The delay was due to conflicts with existing third-party utilities. Utility relocations and construction activities have been substantially completed, and administrative closeout is pending. No public comment or stakeholder sentiment is stated in the document.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- In Committee; recommended for approval
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 with Horizon Contractors, Inc. for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street, extending contract duration by 421 non-compensable calendar days. The project widens NW 84 Avenue from two to four lanes including two dedicated transit lanes. The contract amount remains $7,730,537.60. The adjusted contract duration is 1,201 calendar days. The extension is due to delays from third-party utility relocations. The Transportation Committee forwarded to the BCC with a favorable recommendation on 9/9/2026. The Board of County Commissioners agenda date is 10/6/2026. The project is in Commission District 12. The original contract was approved on January 17, 2023 (Resolution No. R-23-23).
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- Forwarded to BCC with a favorable recommendation by Transportation Committee; pending before the Board
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 between Horizon Contractors, Inc. and Miami-Dade County for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street (Project No. DB21-DTPW-04; Contract No. 20210035), increasing contract duration by 421 non-compensable calendar days. The project widens NW 84 Avenue from two to four lanes, including two dedicated transit lanes, with drainage, roadway reconstruction, sidewalks, lighting, and related infrastructure. The original contract amount was $7,730,537.60 with a total term of 780 calendar days. The adjusted contract duration is 1,201 calendar days. The extension is non-compensable and does not increase the contract amount. The supplemental establishes a full and final release of any claims for additional compensation related to delays. The Transportation Cmte forwarded to BCC with a favorable recommendation on 9/9/2026. Agenda date is 10/6/2026. Status is Before the Board. Introduced 8/19/2026. No public comment or stakeholder sentiment is stated in the document.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- Recommended for approval by Transportation Cmte; pending before the Board
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 between Horizon Contractors, Inc. and Miami-Dade County for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street (Project No. DB21-DTPW-04; Contract No. 20210035). The agreement increases contract duration by 421 non-compensable calendar days, with no change to the contract price. The project involves widening NW 84 Avenue from two to four lanes, including two dedicated transit lanes. The original contract was approved on January 17, 2023 (Resolution No. R-23-23) in the amount of $7,730,537.60 for a total term of 780 calendar days. The adjusted contract duration with this change order is 1,201 calendar days. The supplemental establishes a full and final release of any claims for additional compensation related to delays. The Transportation Committee forwarded to the BCC with a favorable recommendation on 9/9/2026. Agenda date is 10/6/2026. Status is Before the Board. The extension is non-compensable and does not increase the contract amount. The project is in Commission District 12, represented by Commissioner Juan Carlos Bermudez. Delays were due to conflicts with existing third-party utilities. Utility relocations and construction activities have since been substantially completed, and administrative closeout is pending.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- Transportation Committee forwarded to BCC with a favorable recommendation on 9/9/2026; status is Before the Board; agenda date 10/6/2026
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 between Horizon Contractors, Inc. and Miami-Dade County for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street (Project No. DB21-DTPW-04; Contract No. 20210035), increasing contract duration by 421 non-compensable calendar days. The project widens NW 84 Avenue from two to four lanes, including two dedicated transit lanes, with drainage, roadway reconstruction, sidewalks, lighting, and related infrastructure. The original contract was approved on January 17, 2023 (Resolution No. R-23-23) in the amount of $7,730,537.60 for a total term of 780 calendar days, including 720 days to substantial completion. The adjusted contract duration with this change order is 1,201 calendar days. The extension is non-compensable and does not increase the contract amount. The supplemental establishes a full and final release of any claims for additional compensation related to delays caused by third-party utility coordination. Status is In Committee, introduced 8/19/2026, agenda date 10/6/2026, agenda item number 8N. Staff recommendation is approval. No public comment or stakeholder sentiment is stated in the document.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- In Committee; staff recommendation is approval
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 between Horizon Contractors, Inc. and Miami-Dade County for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street, extending contract duration by 421 non-compensable calendar days. The project widens NW 84 Avenue from two to four lanes, including two dedicated transit lanes, with drainage, roadway reconstruction, sidewalks, lighting, and related infrastructure. The original contract was approved on January 17, 2023 (Resolution No. R-23-23) in the amount of $7,730,537.60 for a total term of 780 calendar days. The adjusted contract duration with this change order is 1,201 calendar days. The extension is non-compensable and does not increase the contract amount. The supplemental establishes a full and final release of any claims for additional compensation related to delays caused by third-party utility coordination. The Transportation Cmte forwarded to BCC with a favorable recommendation on 9/9/2026. Agenda date is 10/6/2026. Status is Before the Board. No public comment or stakeholder sentiment is stated in the document.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- Recommended (Transportation Cmte forwarded to BCC with a favorable recommendation on 9/9/2026); Status: Before the Board
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
HORIZON CONTRACTORS TO EXTEND CONTRACT BY 421 DAYS
Resolution approving Supplemental Agreement No. 1 between Horizon Contractors, Inc. and Miami-Dade County for design-build services for roadway improvements to NW 84 Avenue from NW 58 Street to NW 74 Street (Project No. DB21-DTPW-04; Contract No. 20210035). The agreement increases contract duration by 421 non-compensable calendar days, with no change to contract price. The project involves widening NW 84 Avenue from NW 58 Street to NW 74 Street from two to four lanes, including two dedicated transit lanes, drainage, roadway reconstruction, sidewalks, lighting, and related infrastructure. The original contract amount was $7,730,537.60 with a total term of 780 calendar days. The adjusted contract duration is 1,201 calendar days. The Board approved the original contract on January 17, 2023 (Resolution No. R-23-23). The Transportation Cmte forwarded to BCC with a favorable recommendation on 9/9/2026. Agenda date is 10/6/2026. Status is Before the Board. The extension is due to delays from conflicts with existing third-party utilities. The supplemental establishes a full and final release of any claims for additional compensation related to these delays. The project is in Commission District 12, represented by Commissioner Juan Carlos Bermudez. Leo Salgueiro, DTPW Infrastructure Manager, is responsible for monitoring. No adverse findings were identified in due diligence on Horizon Contractors, Inc. Public comment sentiment is not stated.
- Board:
- Transportation Cmte
- Date:
- 2026-09-09
- Type:
- Resolution
- Decision:
- Transportation Cmte forwarded to BCC with a favorable recommendation on 9/9/2026; pending BCC assignment; agenda date 10/6/2026
- Address:
- NW 84 Avenue from NW 58 Street to NW 74 Street
- Applicant:
- Horizon Contractors, Inc.
See the actual businesses behind these numbers
Get the real filings, with addresses and officers, backed by a 14-day money-back guarantee.
Create your account